OEHME, VAN SWEDEN & ASSOCIATES v. PINCHUK et al
Filing
13
MEMORANDUM OPINION. Signed by Judge John D. Bates on 11/06/2012. (lcjdb1)
UNITED STATES DISTRICT COURT
FOR THE DISTRICT OF COLUMBIA
OEHME, VAN SWEDEN &
ASSOCIATES, INC.,
Petitioner,
v.
Civil Action No. 12-05 (JDB)
MAYPAUL TRADING & SERVICES
LTD.; ELENA PINCHUK,
Respondents.
MEMORANDUM OPINION
Before the Court is petitioner Oehme, van Sweden & Associates, Inc.'s ("OvS") motion
for confirmation of an arbitration award in its favor and [9] respondents Maypaul Trading &
Services Ltd. and Elena Pinchuk's motion to vacate that award.1 For the reasons that follow, the
award will be confirmed in its entirety.
BACKGROUND
The dispute in this case concerns a contract for architectural and landscape design
services on a property in Ukraine. Resp'ts' Mot. to Vacate Arbitration Award [ECF 9] ("Mot.
Vacate") at 1. OvS is a globally recognized landscape architecture firm based in Washington,
DC. Tr. Arbitration Hr'g [ECF 9, Ex. C] ("Hearing Tr.") at 18. Victor and Elena Pinchuk are a
prominent Ukranian couple. Id. at 19. In 2004, OvS met with the Pinchuks to discuss potential
projects on the grounds of a property in Kiev, Ukraine (the "Property"). Id. at 53-54. According
1
OvS filed its motion for confirmation in the Superior Court of the District of Columbia,
and respondents removed the case to this Court. See Notice of Removal [ECF 1].
1
to OvS's CEO, Lisa Delplace, the Pinchuks referred to the Property as their own, and on the
Property was a house under construction that was to be their home. Id. at 67, 80. The Property
was in fact owned, from September 3, 2004 to the present, by Svit Shylahiv Transportation and
Forwarding Company, LLC ("Svit Shylahiv"). Mot. Vacate, State Certificate of the Plot of Land
Ownership Right [ECF 9, Ex. G]. Svit Shylahiv is owned by Pantoho Limited, a company of
Cyprus controlled by a group of entities that have an "Investment Advisory Agreement" with
EastOne Group Limited. Mot. Vacate, Investment Advisory Agreement #24 [ECF 9, Ex. N]
("EastOne-Pantoho Agreement") (signed March 20, 2009; effective July 1, 2008); id., Joint
Stipulation of Uncontested Facts [ECF 9, Ex. Q] ("Joint Stip.") at 2. EastOne Group is solely
owned by Victor and Elena Pinchuk, and under the investment advisory agreement with Pantoho,
it has rights to give "advisory and consulting services" to Pantoho in relation to, among other
things, "operations and strategic planning," "financial advisory matters," and "the selection,
retention and supervision of top-managers of [Pantoho]'s subsidiaries." See EastOne-Pantoho
Agreement ¶¶ 1.1, 1.2, 1.2.1, 1.2.4, 1.2.7; Joint Stip. at 2. The investment advisory agreement
does not give EastOne Group ownership rights in Pantoho or its subsidiaries (including Svit
Shylahiv).
After the initial meeting with the Pinchuks, OvS performed landscape design services on
the Property. Id. at 80. At first, no contract governed the parties' relationship; OvS sent invoices
to the Pinchuks for its services and was paid accordingly through a company called Fortlex
Limited. Id. at 80, 82. The house on the Property was later razed, and the Pinchuks asked OvS
to submit a design proposal for a new house to be built on the Property. Id. at 91. OvS
submitted a "master plan" that included the house, interior courtyard, lily pool, several gardens,
2
and rear garden terrace. Id. at 96. OvS, primarily through Lisa Delplace, and the Pinchuks,
through intermediaries Aurika Dmitrieva, Konstantin Ussar, and others, then negotiated a
contract to govern OvS's services going forward. Id. at 90-93, 96-99. Early letter proposals
circulated by OvS included signature lines for the Pinchuks and did not include an arbitration
clause. Mot. Vacate, 2004-2006 Letter Proposals [ECF 9, Ex. I]. Later, more formal draft
agreements contemplated a "legal entity" as OvS's counterparty to the contract and included an
arbitration clause. Id., 1/15/2007 Draft Agreement [ECF 9, Ex. L] (Agreement entered into by
OvS and "___ , a legal entity duly organized and operating under the laws of ___, with its
registered office at: ___, represented by ___ (hereinafter referred to as the 'Owner')").
Throughout the negotiations, Delplace believed that the Pinchuks owned the Property and that,
notwithstanding the space for a "legal entity" on draft agreements, the Pinchuks would be
designated as the owner on the final agreement. Hearing Tr. at 142; 212-15. But on the day the
contract was to be executed, Delplace learned that Maypaul would be the other signatory. Id. at
150. Delplace had never heard of Maypaul before that date but said that Ussar told her that
Maypaul was "Elena's representative." Id. at 150, 158-59. Delplace, who said she had "no
reason to believe otherwise," signed a contract with Maypaul on behalf of OvS. See id. at 259.
On paper, however, Maypaul did not sign the contract as the Pinchuks' "representative."
Maypaul is a company of Cyprus in which the Pinchuks are not officers, directors, or
shareholders. Mot. Vacate, Certificate [ECF 9, Ex. O]. Svit Shylahiv, through Transport
Investments LLC,2 had contracted with Maypaul "to provide all necessary services in connection
2
Respondents state that because neither Svit Shylahiv nor Transport Investments is a
party in this case, they do not have the agreement between Svit Shylahiv and Transport
Investments. Mot. Vacate at 9 n.1. The Court assumes that this agreement exists based on
3
with the search and organization of the landscape services" on the Property. Mot. Vacate,
1/10/2007 Agency Agreement [ECF 9, Ex. M] ("Transport-Maypaul Agreement") ¶ 1.1. The
"Agency Agreement" between Transport Investments and Maypaul authorized Maypaul to "(i)
sign any documents or agreements; (ii) effect all necessary payments; and (iii) make any other
settlements, in any event relating to the performing Services." Id. ¶ 1.3. On the Pinchuks' side,
before the signing of the contract, Ms. Pinchuk had entered into a preliminary lease agreement
with Svit Shylahiv, in which Svit Shylahiv had agreed to lease the Property to Ms. Pinchuk upon
completion of construction and improvements thereon. Mot. Vacate, 8/1/2006 Prelim.
Agreement [ECF 9, Ex. B] ("Prelim. Lease") ¶¶ 1.1, 3.3.2 The preliminary lease agreement gave
Ms. Pinchuk the rights "to take part in choosing, ordering and performing interior
works . . . territory improvement works [on the Property]" and "to bring in reasonable critical
comments and desires in respect of the . . . construction, furnishing and improvement [on the
Property]." See id. ¶ 3.2.
On February 2, 2007, OvS and Maypaul, designated as the "Owner," entered into the
agreement ("Agreement") that is at the heart of this dispute. Agreement [ECF 9, Ex. A] at 1.
The Agreement does not mention Elena Pinchuk or her husband. In the Agreement, OvS agreed
to provide landscape design services on the Property as specified in the Agreement and an
addendum thereto, and additional services "if requested, subject to an agreed upon revision in the
scope of services and authorized fee(s)." Id. ¶¶ 1.1, 1.2. In return, Maypaul agreed to pay OvS
respondents' representation.
2
Ms. Pinchuk entered into the preliminary lease agreement under her maiden name, Elena
Franchuk.
4
$447,600 in twenty monthly installments, plus reimbursable expenses not to exceed 40% of the
monthly installment amount absent prior written approval by Maypaul. Id. ¶¶ 7.1, 7.3, addendum
¶¶ 6.3.1, 6.4. Under the Agreement, Maypaul was "not obliged to any payments that [were] not
specified in [the addendum] unless negotiated in advance and authorized in writing." Id. ¶ 7.5.
All work was to be completed by July 1, 2008. Id. addendum ¶ 5.1. OvS was not liable for
"approvals or construction delays outside [its] scope of work," but any delays were to be
"documented in advance and approved by both parties." Id. ¶ 6.4. Services not included in the
Agreement or addendum or "not customarily furnished in accordance with generally accepted
[OvS] practice," if required, were to be provided "under separate agreement." Id. ¶ 8.1.
The Agreement contains a number of provisions that are pertinent here, including: (1) an
integration clause stating that the Agreement "supersedes all prior negotiations, representations
or agreement, either written or oral" and "may be amended only by written instrument signed by
both Owner and [OvS]," id. ¶ 9.3; (2) a clause stating that the Agreement is "binding upon and
shall inure to the benefit of the parties and their respective successors, permitted assigns, legal or
personal representative, or partners," id. ¶ 9.2; (3) a District of Columbia choice of law clause, id.
¶ 9.1;3 and (4) the following arbitration clause:
All claims, disputes and other matters in question between the parties to this
Agreement, arising out of or relating to this Agreement or the breach thereof, shall
be decided by arbitration in the District of Columbia in accordance with the
Construction Industry Arbitration Rules of the American Arbitration Association
then obtaining unless the parties mutually agree in writing otherwise. This
Agreement to arbitrate and any agreement to arbitrate with an additional person or
persons duly consented to by the parties to this Agreement shall be specifically
3
"This Agreement is deemed to be negotiated and executed in the District of Columbia, is
to be performed at least in significant part in the District of Columbia, is governed by its law, and
may be enforced in that jurisdiction." Agreement ¶ 9.1.
5
enforceable under the prevailing arbitration law. Arbitration fees may be
assessed.
Id. ¶ 4.1.
After the Agreement was executed, Ms. Pinchuk played a central role in directing the
services provided by OvS under the Agreement. For example, representatives of Ms. Pinchuk
and Svit Shylahiv referred to Ms. Pinchuk as the "client" or "customer" and looked to Ms.
Pinchuk for approval on design, price, and payment issues, and Ms. Pinchuk communicated with
OvS about the Agreement in person, by email, and through her representatives. See Arbitration
Award [ECF 9, Ex. D] ("Award") at 19-23; Hearing Tr. at 265-66; 297-98; 397; 477-97. At the
request of Ms. Pinchuk or her representatives, OvS made significant modifications to the
landscape design plans, and as a result of these changes and delays in the construction of the
house (that were beyond OvS's control), OvS's completion of the work was delayed. See Award
at 23-24; Hearing Tr. at 112-13; 186-87; 189-90. As early as December 2007, OvS raised the
subject of an addendum covering additional services beyond the Agreement's July 1, 2008
completion date. See Hearing Tr. at 188. OvS discussed the addendum with representatives of
Ms. Pinchuk in the ensuing months but did not send them a draft addendum until July 2008. Id.
at 191. At that time, OvS had completed all but the final phase of the project set out in the
original Agreement. Id. at 197. OvS continued to provide services on the Property and asked for
additional payments for these services. Several drafts of the addendum were circulated, but none
was executed, and in October 2008 OvS stopped work on the Property. See id. at 128; Award at
24; Mot. Vacate, Emails [ECF 9, Ex. P]. Maypaul paid OvS in full under the original Agreement
in the amounts of $447,556.25 for professional fees (which included $50,000 allotted to the not-
6
yet-completed final phase) and $175,016.64 for reimbursable expenses. See Agreement
addendum ¶¶ 5.1, 6.1; Mot. Vacate, Kiev Project Summary [ECF 9, Ex. V] ("Kiev Project
Invoice"). The final phase of the project was never completed, and Maypaul refused to make any
additional payments.
On April 13, 2010, OvS filed a demand for arbitration under the Construction Industry
Arbitration Rules of the American Arbitration Association ("AAA Construction Rules") against
Ms. Pinchuk and Maypaul. OvS's Opp. to Mot. Vacate [ECF 10] ("Opp."), Demand for
Arbitration [ECF 10, Ex. 2]. OvS alleged that respondents had breached the Agreement and had
been unjustly enriched because respondents had not paid OvS for services it provided after July
1, 2008. Id. at 5-7. OvS sought damages, or in the alternative, restitution, in the amount of
$169,933.96,4 plus interest at 18% per annum, attorney's fees, and costs. Id. at 7. Ms. Pinchuk
objected to the jurisdiction of the arbitrator, and Maypaul filed a counterclaim for $50,000 based
on OvS's non-completion of the project's final phase. Mot. Vacate, Resp'ts' Answering Statement
& Statement of Countercls. [ECF 9, Ex. W] at 4-5. After submissions from the parties on the
issue of arbitral jurisdiction, the arbitrator determined that OvS had made a prima facie showing
of jurisdiction over Ms. Pinchuk and deferred final resolution of the issue until after the hearing.
See Award at 4-5. The arbitrator held hearings in February and March 2011, at which Ms.
Pinchuk appeared specially to contest jurisdiction. See Hearing Tr. at 5. The arbitrator issued an
award for OvS on October 26, 2011. Award at 53.
The arbitrator concluded, first, that he had jurisdiction over Ms. Pinchuk, a nonsignatory
4
The amount sought accounted for a "credit" of $50,000 to Maypaul for the work that
was paid for but not completed. See Award at 42; Kiev Project Invoice.
7
to the Agreement, based on theories of disregard of the corporate personality, estoppel, and
agency. See id. at 26-31. He next held in favor of OvS on the merits, concluding that despite
there being no modifications to the Agreement in writing, the parties had agreed to material
modifications of the scope and duration of work under the Agreement, and that Maypaul and Ms.
Pinchuk breached the Agreement as modified by not paying OvS for professional fees and
expenses incurred after June 30, 2008. See id. at 40, 44. The arbitrator concluded, in the
alternative, that OvS was entitled to restitution in quantum meruit. Id. at 45-46. The arbitrator
awarded OvS: (1) damages in the amount of $281,710.14 (OvS's professional fees less $50,000,
plus reimbursable expenses, plus interest at a rate of 18% per annum through October 15, 2011);
(2) attorney's fees and costs in the amount of $178,985.46; (3) $26,290.00 as reimbursement for
arbitration fees and expenses; and (4) post-award interest on the total at a rate of 3% per annum
beginning 30 days after the date of the award. Id. at 47-49, 52; see also Kiev Project Invoice.
The arbitrator denied Maypaul's counterclaim because the damages sought by OvS had already
been reduced by $50,000. Award at 48.
DISCUSSION
The parties agree that District of Columbia law governs the Agreement and that the
District of Columbia Revised Uniform Arbitration Act ("DCRAA"), D.C. Code §§ 16-4401 et
seq., applies to the Award. See Agreement ¶ 9.1; Mot. Vacate at 1, 12, 30; Opp. at 1, 7 n.7, 9
n.9.5
5
Courts have held that a "generic" choice-of-law clause, such as that here, see Agreement
¶ 9.1, is insufficient to preclude application of the Federal Arbitration Act ("FAA"). See, e.g.,
Mastrobuono v. Shearson Lehman Hutton, Inc., 514 U.S. 52, 59, 62 (1995); Foulger-Pratt
Residential Contracting, LLC v. Madrigal Condos., LLC, 779 F. Supp. 2d 100, 109 & n.9
(D.D.C. 2011) (collecting cases). Because the parties agree that the DCRAA applies, however,
8
Judicial review of arbitration awards is "extremely limited." Bolton v. Bernabei & Katz,
PLLC, 954 A.2d 953, 959 (D.C. 2008) (quoting Lopata v. Coyne, 735 A.2d 931, 940 (D.C.
1999)); accord Foulger-Pratt, 779 F. Supp. 2d at 113. Courts generally "will not set aside an
arbitration award for errors of either law or fact made by the arbitrator." Dolton v. Merrill Lynch,
Pierce, Fenner & Smith, Inc., 935 A.2d 295, 298 (D.C. 2007) (internal quotation marks and
citation omitted). Under the DCRAA, a court may vacate an arbitration award only on one of six
grounds set by statute or on "other reasonable ground." D.C. Code § 16-4423(a)-(b). An
arbitration award may also be vacated if the arbitrator "manifestly disregarded the law." See
Cathedral Ave. Coop., Inc. v. Carter, 947 A.2d 1143, 1151 (D.C. 2008) (internal quotation marks
and citation omitted); Shore v. Groom Law Grp., 877 A.2d 86, 91 (D.C. 2005). But see Laszlo
N. Tauber, M.D. & Assocs. v. Trammell Crow Real Estate Servs., 738 A.2d 1214, 1217 n.5
(D.C. 1999).6
Respondents contend that the Award against them should be vacated under the DCRAA.
Ms. Pinchuk asserts one of the six statutory grounds, arguing that as to her, "[t]here was no
agreement to arbitrate" because she was not a party to the Agreement. See D.C. Code § 164423(a)(5). Maypaul argues that the arbitrator "manifestly disregarded the law" in ruling for OvS
and because "there is nothing in the D.C. arbitration law that conflicts with the policy behind the
FAA," the Court will apply the DCRAA. See Foulger-Pratt, 779 F. Supp. 2d at 109-10 & n.10;
see also Ekstrom v. Value Health, Inc., 68 F.3d 1391, 1393, 1395-96 (D.C. Cir. 2004).
6
It is unclear whether the "manifest disregard" standard remains an independent basis for
vacating an arbitration award under the FAA after the Supreme Court's decision in Hall St.
Assocs. v. Mattel, Inc., 552 U.S. 576 (2008). See Stolt-Nielsen S.A. v. AnimalFeeds Int'l Corp.,
130 S. Ct. 1758, 1768 n.3 (2010). The Court will assume that "manifest disregard of the law" is
a ground for vacatur falling within the "other reasonable ground" language of the DCRAA. See
A1 Team Holdings, LLC v. Bingham McCutchen LLP, 998 A.2d 320, 324-25 & n.7, 327 (D.C.
2010) (discussing D.C. Code § 16-4423(b)).
9
on the merits. The Court will address respondents' arguments in turn.
I.
Arbitral Jurisdiction over Ms. Pinchuk
Before deciding the arbitrability question – here, whether Ms. Pinchuk, as a nonsignatory
to the Agreement, can be compelled to arbitrate under the Agreement – the Court must decide a
threshold question: "'who has the primary power to decide arbitrability.'" See First Options of
Chicago, Inc. v. Kaplan, 514 U.S. 938, 943 (1995). This question "turns upon what the parties
agreed about that matter[:] Did the parties agree to submit the arbitrability question itself to
arbitration?" Id. If so, the Court will defer to the arbitrator's decision on arbitrability, setting it
aside "only in certain narrow circumstances." Id.; see also D.C. Code § 16-4423(a)-(b). But if
the parties did not agree to arbitrate the arbitrability question, the Court will decide that question
de novo. See First Options, 514 U.S. at 943. Courts do not presume that parties agreed to
arbitrate arbitrability and will find that they did only if there is "clear and unmistakable evidence"
of such an agreement. See id.; see also Howsam v. Dean Witter Reynolds, Inc., 537 U.S. 79, 83
(2002); AT & T Techs., Inc. v. Commc'ns Workers of Am., 475 U.S. 643, 649 (1986). To
determine whether "clear and unmistakable evidence" exists, courts apply principles of ordinary
state-law contract formation. First Options, 514 U.S. at 944.
A.
Did Ms. Pinchuk clearly and unmistakably agree to arbitrate arbitrability?
Relying on First Options, OvS argues that Ms. Pinchuk's conduct during the arbitration
shows that she clearly and unmistakably agreed to arbitrate arbitrability. Opp. at 8-13. OvS
stresses that Ms. Pinchuk submitted the question of arbitral jurisdiction to the arbitrator, citing,
among other things, her statement of issues for decision by the arbitrator and her failure to "assert
that the Arbitrator lacked the authority to decide arbitral jurisdiction or reserve the right for the
10
court to decide the question." Opp. at 11. OvS also asserts that Ms. Pinchuk's consent to
application of the AAA Construction Rules, and specifically Rule 9, which gives the arbitrator
"power to rule on his or her own jurisdiction," is further evidence of a "clear and unmistakable"
agreement to arbitrate arbitrability. Id. at 12.
The Court is not persuaded. As the Supreme Court stated in First Options, "merely
arguing the arbitrability issue to an arbitrator does not indicate a clear willingness to arbitrate that
issue." 514 U.S. at 946. Here, like the nonsignatories to the arbitration agreement in First
Options, see id., Ms. Pinchuk consistently and "forcefully object[ed]" to the arbitrator deciding
the dispute, as noted by the arbitrator in his initial procedural order, at the hearing, and in the
Award. Procedural Order No. 1 [ECF 10, Ex. 5] at 1 ("Nothing in this Procedural Order is to be
understood to constitute a waiver of Pinchuk's objections to jurisdiction, and she reserves all
rights to contest jurisdiction, both before the Arbitrator or in any other appropriate venue.");
Hearing Tr. at 7 ("I note that there is a jurisdictional objection by Ms. Pinchuk in these
proceedings. That objection has been preserved."); Award at 26 ("Ms. Pinchuk has consistently
objected to arbitral jurisdiction over her in this dispute."). She also agreed to produce documents
in discovery "subject to reserving the right to challenge jurisdiction after the Arbitrator's final
ruling on the issue" and appeared specially at the hearing to contest jurisdiction. Resp'ts' Reply,
12/28/2010 Email [ECF 12, Ex. A] at 7; Hearing Tr. at 5. Ms. Pinchuk's conduct during the
arbitration, far from clearly establishing her agreement to be bound by the arbitrator's decision on
arbitrability, showed that she "did not want the arbitrator[] to have binding authority over [her]."
See First Options, 514 U.S. at 946.
That the parties agreed on the conduct of the arbitration in accordance with the AAA
11
Construction Rules does not change the Court's conclusion. Ms. Pinchuk so agreed "[s]ubject to"
her objections to arbitral jurisdiction. Procedural Order No. 1, at 1. Incorporation of AAA rules
giving an arbitrator power to decide arbitrability may constitute "clear and unmistakable
evidence" as required by First Options. See, e.g., Qualcomm Inc. v. Nokia Corp., 466 F.3d 1366,
1373 (Fed. Cir. 2006); Contec Corp. v. Remote Solution Co., 398 F.3d 205, 208-09 (2d Cir.
2005); Grynberg v. BP P.L.C., 585 F. Supp. 2d 50, 54-55 (D.D.C. 2008) (citing Avue Techs.
Corp. v. DCI Grp., L.L.C., No. 06-327 (JDB), 2006 WL 1147662, at *6-7 (D.D.C. Apr. 28,
2006)). But the cases cited by OvS on this point did not involve a nonsignatory's obligation to
arbitrate. In Grynberg, for example, the plaintiffs argued that their claim was beyond the scope
of an arbitration agreement with the defendants but did "not seriously contest the existence or
validity of the arbitration agreement." 585 F. Supp. 2d at 53; see also Contec, 398 F.3d at 211
(holding that signatory to arbitration agreement was compelled to arbitrate question of
arbitrability with nonsignatory); Avue Technologies, 2006 WL 1147662, at *5. A signatory to a
contract has clearly and unmistakably agreed to its terms, but that is not necessarily true of a
nonsignatory. Here, Ms. Pinchuk did not sign the Agreement incorporating the AAA
Construction Rules, she agreed to arbitrate under these Rules subject to reservation of "all rights
to contest jurisdiction, both before the Arbitrator or in any other appropriate venue," and she did
not otherwise forfeit her right to judicial review of arbitrability. See Davis v. Chevy Chase Fin.
Ltd., 667 F.2d 160, 167-68 (D.C. Cir. 1981); Grad v. Weatherholt Galleries, 660 A.2d 903, 90708 (D.C. 1995); Procedural Order No. 1, at 1 (emphasis added). Because Ms. Pinchuk did not
clearly and unmistakably agree to arbitrate arbitrability, the Court will independently decide
whether she is bound to arbitrate under the Agreement.
12
B.
Is Ms. Pinchuk bound to arbitrate under the Agreement?
A nonsignatory to an arbitration agreement may be bound by that agreement under
traditional principles of contract and agency law. See Arthur Andersen LLP v. Carlisle, 556 U.S.
624, 631 (2009) (citing 21 Richard A. Lord, Williston on Contracts § 57:19, at 183 (4th ed.
2001)). The theories for binding nonsignatories to arbitration agreements include incorporation
by reference, assumption, agency, veil piercing/alter ego, estoppel, and third-party beneficiary.
See id.; Bridas S.A.P.I.C. v. Gov't of Turkmenistan, 345 F.3d 347, 356 (5th Cir. 2003);
Thompson-CSF, S.A. v. Am. Arbitration Ass'n, 64 F.3d 773, 776 (2d Cir. 1995). Here, the
arbitrator held that Ms. Pinchuk was bound by the Agreement's arbitration clause on the
alternative theories of disregard of corporate personality (akin to piercing the corporate veil),
equitable estoppel, and agency. See Award at 26-31. Ms. Pinchuk argues that none of these
theories properly apply here. See Mot. Vacate at 14.
1.
Veil piercing/alter ego
Under District of Columbia law, a party seeking to pierce the corporate veil and thereby
establish that a corporation is an alter ego of an individual must show by "affirmative evidence"
(1) "unity of ownership and interest" between the corporation and the individual and (2) "use of
the corporate form to perpetrate fraud or wrong." See Jackson v. Loes Wash. Cinemas, Inc., 944
A.2d 1088, 1095 (D.C. 2008) (internal quotation marks and citation omitted). Unity of
ownership and interest may be established "by showing domination and control of a corporation."
Vuitch v. Furr, 483 A.2d 811, 816 (D.C. 1984). The arbitrator did not apply this two-pronged
test per se, but in concluding that Ms. Pinchuk "clearly disregarded the corporate personality of
Maypaul," the arbitrator effectively found that the "unity of ownership and interest" prong was
13
satisfied. He found that the Property was "owned and controlled by a company owned and
controlled by the Pinchuks, Svit Shylahiv"; that "[t]he rights and responsibilities of the 'Owner'
under the Contract were exercised by individuals employed by companies owned and controlled
by the Pinchuks, acting at the direction of the 'Client' – Ms. Elena Pinchuk"; and that "Ms.
Pinchuk was responsible for making payments under the Contract, regardless of Maypaul's
formal obligation." Award at 27-29.
Ms. Pinchuk disputes these findings, and indeed Maypaul is not formally owned or
controlled by Ms. Pinchuk. The Court need not resolve this factual dispute, however, because
even assuming that there was unity of ownership and interest between Maypaul and Ms. Pinchuk,
that alone would not be sufficient to pierce the corporate veil. OvS has not offered – to the
arbitrator or to this Court – any "affirmative evidence" of fraud. See Jackson, 944 A.2d at 1095.
The arbitrator did not cite fraud or deception in the Award, nor does the Court see any on this
record. See id. Accordingly, the Court holds that Ms. Pinchuk cannot be compelled to arbitrate
by piercing Maypaul's corporate veil.
2.
Estoppel
The doctrine of equitable estoppel may preclude a party from "asserting that the lack of
his signature on a written contract precludes enforcement of the contract's arbitration clause when
he has consistently maintained that other provisions of the same contract should be enforced to
benefit him." Int'l Paper Co. v. Schwabedissen Maschinen & Anlagen GMBH, 206 F.3d 411,
418 (4th Cir. 2000); see also Wash. Mut. Fin. Grp., LLC v. Bailey, 364 F.3d 260, 267 (5th Cir.
14
2004).7 A nonsignatory may be bound to arbitrate if he or she "knowingly seek[s] and obtain[s]
'direct benefits' from [a] contract," "seek[s] to enforce the terms of that contract," or "assert[s]
claims that must be determined by reference to that contract." See Noble Drilling Servs., Inc. v.
Certex USA, Inc., 620 F.3d 469, 473 (5th Cir. 2010). Citing International Paper and American
Bureau of Shipping v. Tencara Shipyard S.P.A., 170 F.3d 349, 353 (2d Cir. 1999), the arbitrator
found that Ms. Pinchuk "was, and considered herself to be, the client and customer of OvS" and
"claim[ed] the direct benefit of the Contract," and as such was equitably estopped from denying
an obligation to arbitrate under that same contract. Award at 30. The arbitrator based this
conclusion primarily on a January 26, 2009 email from Ms. Pinchuk (then Franchuk) to Lisa
Delplace. See id. at 28-29. The email is written in the first-person singular and plural and
contains statements suggesting that Ms. Pinchuk, in the arbitrator's words, "was responsible for
payments under the Contract" and "expected performance of the Contract for her reciprocal
benefit in response." Id. (citing Mot. Vacate, 1/26/2009 Email [ECF 9, Ex. S]).8
Ms. Pinchuk contends that neither this email nor any "benefit" she received from OvS's
performance of the contract estops her from avoiding arbitration. Mot. Vacate 22-24. The Court
7
The Court is not aware of any District of Columbia cases applying the doctrine of
equitable estoppel to nonsignatories to an arbitration agreement and hence looks to federal court
cases applying the doctrine in this context. See Wash. Mut., 364 F.3d at 267 n.6.
8
See, e.g., 1/26/2009 Email ("[W]e agreed [on] a substantial price up front for the work
to be undertaken, and we have been making regular and timely payments to you under the
Contract to the total of US $622,572.89, which shows our trusting relationship with you and our
expectation of the respective timely performance of quality services on your side."); id. ("Having
already paid you the money due under the Contract, in the spirit of good faith we would strongly
ask that you complete the work on the garden as soon as practicable, following which we will
consider your invoices issued under the Contract and in line with our understanding as set out in
this letter.").
15
agrees. On the one hand, Ms. Pinchuk, through the January 26, 2009 email and other conduct
influencing the design services on the Property, has arguably sought to "enforce" the Agreement's
terms – for example, the caps on total fees and reimbursable expenses. See Noble Drilling, 620
F.3d at 473; 1/26/2009 Email. And as a future lessee of the Property, Ms. Pinchuk stood to
benefit from OvS's performance. Hence, there is an equitable argument for holding Ms. Pinchuk
to the Agreement and its arbitration clause based on her undisputed role in the Agreement's
formation and performance, and for saying that in fairness she must abide by its terms. On the
other hand, the Court "must be careful about disregarding the corporate form and treating a nonsignatory like a signatory." See E.I. Dupont de Nemours & Co. v. Rhone Poulenc Fiber & Resin
Intermediates, S.A.S., 269 F.3d 187, 201 (3d Cir. 2001). Most significant here, Ms. Pinchuk has
not asserted any claims against OvS. See Noble Drilling, 620 F.3d at 473. In the mine run of
cases holding a nonsignatory bound under equitable estoppel, including those doing so based on
the receipt of "direct benefits" rather than the assertion of contract-based claims, the nonsignatory
had sued the signatory based in part on the agreement at issue. See Bridas, 345 F.3d at 362
(collecting cases); Int'l Paper, 206 F.3d at 418; Am. Bureau of Shipping, 170 F.3d at 353
(requiring nonsignatory owners to arbitrate their claims against signatory because owners had
received direct benefits of lower insurance rates and ability to sail under French flag); see also
Hellenic Inv. Fund, Inc. v. Det Norske Veritas, 464 F.3d 514, 518 (5th Cir. 2006). That Ms.
Pinchuk not only has not sued on the contract but has not sued at all weighs strongly against
application of estoppel in this case. See Bridas, 345 F.3d at 362.
Moreover, even if equitable estoppel might be appropriate in some cases where a
nonsignatory brings no claims against a signatory, any benefits Ms. Pinchuk received from OvS's
16
performance of the Agreement were not sufficiently "direct" to estop her here. See, e.g., MAG
Portfolio Consultant, GMBH v. Merlin Biomed Grp. LLC, 268 F.3d 58, 61 (2d Cir. 2001) ("The
benefits must be direct – which is to say, flowing directly from the agreement."). The
improvements to the Property "flowing directly" from the Agreement directly benefitted Svit
Shylahiv, who owned the Property, and may have directly benefitted Ms. Pinchuk in the future,
had she leased the Property. See id. But they did not directly benefit Ms. Pinchuk during the
duration of the Agreement, as she did not own the Property and had signed only a "preliminary"
agreement to lease it, a final lease agreement having been contingent on the completion of
construction on the Property. See Prelim. Lease ¶ 3.3. And Ms. Pinchuk's rights under the
preliminary lease to comment on and "take part in choosing, ordering and performing" the design
and construction on the Property gave her tangible rights in the Property only if a final lease
agreement was executed. See id. ¶ 3.1. In short, Ms. Pinchuk received only indirect, contingent
benefits from the Agreement and hence is not equitably estopped from avoiding arbitration.
3.
Third-party beneficiary
The doctrine of third-party beneficiary is similar to the doctrine of equitable estoppel.
Although the arbitrator did not expressly rely on it, he quoted from a case discussing third-party
beneficiary status to find that the Agreement was "'directly and unequivocally intended to
benefit'" Ms. Pinchuk, and Ms. Pinchuk disputes that she was a third-party beneficiary. See
Award at 29 (quoting Nortel Networks, Inc. v. Gold & Appel Transfer, S.A., 298 F. Supp. 2d 81,
90 (D.D.C. 2004)); Mot. Vacate at 29-30. The Court will therefore consider the application of
third-party beneficiary doctrine to this case.
"Third-party beneficiary status requires that the contracting parties had an express or
17
implied intention to benefit directly" the party urged to be a third-party beneficiary. See Fort
Lincoln Civic Ass'n v. Fort Lincoln New Town Corp., 944 A.2d 1055, 1064 (D.C. 2008)
(internal quotation marks and citation omitted). In contrast to equitable estoppel, which looks to
the parties' conduct "after the contract was executed," third-party beneficiary theory looks to the
parties' intentions "at the time the contract was executed." See Dupont, 269 F.3d at 200 n.7. "An
indirect interest in the performance of the undertakings is insufficient." Fort Lincoln, 944 A.2d
at 1064 (internal quotation marks, citation, and alteration omitted).
The Agreement here makes no reference to Ms. Pinchuk, as a third-party beneficiary or
otherwise. To the contrary, the Agreement provides that it "shall be binding upon and inure to
the benefit of the parties and their respective successors, permitted assigns, legal or personal
representative, or partners." Agreement ¶ 9.2. This provision suggests that the parties did not
"directly and unequivocally" intend the Agreement to benefit Ms. Pinchuk, since it expressly lists
the Agreement's beneficiaries and does not include Ms. Pinchuk among them. See DuPont, 269
F.3d at 196; Sazerac Co. v. Falk, 861 F. Supp. 253, 258 (S.D.N.Y. 1994). Assuming that,
notwithstanding this provision, the parties could have impliedly intended Ms. Pinchuk to be a
third-party beneficiary of the Agreement, they did not do so. Ms. Pinchuk's role in negotiating
the Agreement, "without more, has nothing to with whether [she] was a third party beneficiary,"
see DuPont, 269 F.3d at 197, and as discussed above, her interest in the performance of the
Agreement was only indirect, see Fort Lincoln, 944 A.2d at 1064 (requiring that parties to
contract intend to benefit third-party beneficiary "directly"). Finally, Ms. Pinchuk has not
asserted any claims based on her alleged third-party beneficiary status. See Bridas, 345 F.3d at
363; Dupont, 269 F.3d at 197. Hence, Ms. Pinchuk is not bound to arbitrate as a third-party
18
beneficiary.
4.
Agency
A principal may be bound by an arbitration agreement signed by its agent if the agent had
actual or apparent authority to act on behalf of the principal. See Thompson-CSF, 64 F.3d at
776; Restatement (Third) of Agency § 6.01 (2006).9 Actual authority is determined from the
principal's manifestations to the agent. See Makins v. District of Columbia, 861 A.2d 590, 593
(D.C. 2004). Apparent authority, on the other hand, depends on the principal's manifestations to
a third person, and "arises when a principal places an agent in a position which causes a third
person to reasonably believe the principal had consented to the exercise of authority the agent
purports to hold." See Sigal Constr. Corp. v. Stanbury, 586 A.2d 1204, 1218-19 (D.C. 1991).
"Critical" to apparent authority is "the third-party's perception of the agent's authority." Id. at
1219.
In this case, there is no evidence that Ms. Pinchuk manifested her assent to Maypaul to
act on her behalf.10 The question, then, is whether Maypaul, the alleged agent, had apparent
9
Extrinsic evidence, although not admissible to contradict or vary the terms of a written
contract, is admissible to identify the contracting parties if their identity is in dispute. See
Affordable Elegance Travel, Inc. v. Worldspan, L.P., 774 A.2d 320, 327 (D.C. 2001); see also
MJR Int'l, Inc. v. Am. Arbitration Ass'n, No. 06-0397, 2009 WL 2824102, at *7 n.6 (S.D. Ohio
Aug. 26, 2009) ("If the Court were forced to rely on nothing but the terms of the contract
between the alleged agent and the third party to determine whether a nonsignatory principal could
be bound, a principal could almost always avoid liability for contracts enter[ed] into on its behalf
by an agent merely by refusing to sign the contract itself. That result would be nonsensical given
the overriding legal tenet that a nonsignatory principal is bound by his agent's contracts."), aff'd
398 F. App'x 115 (6th Cir. 2010); Restatement (Third) Agency § 6.01 cmt. c ("The
parol-evidence rule does not bar proof that an agent made a contract on behalf of a principal.").
10
The agency agreement between Transport Investments and Maypaul in fact disclaims
any actual authority on Maypaul's part to bind its principal to agreements entered into with third
parties. See Transport-Maypaul Agreement ¶ 1.3 ("For the avoidance of any doubt, the Parties
19
authority to bind Ms. Pinchuk, the alleged principal, based on Ms. Pinchuk's dealings with OvS,
the third party. The arbitrator, however, answered a different question. The arbitrator concluded
that OvS reasonably believed that "Ms. Dmitrieva, Mr. Ussar, Mr. Shapovalov and Mr.
Chernyavskiy, among others" acted as Ms. Pinchuk's agents in "all aspect[s] of contract
performance." Award at 31 (emphasis added). But neither the arbitrator nor OvS point to any
authority that would permit a court to bind a nonsignatory principal to a contract based on the
conduct of nonsignatory agents regarding the performance of that contract after it had already
been executed. Cf., e.g., Bridas, 345 F.3d at 358 ("Bridas has set forth ample evidence regarding
the extent to which Turkmenneft was controlled by the Government subsequent to the signing of
the JVA. Such evidence, however, does not establish that Turkmenneft had the apparent
authority to bind the Government in 1993."). The key conduct here is Ms. Pinchuk's
manifestations – made directly and through her representatives – to OvS. See Restatement
(Third) Agency § 2.03 cmt. c ("[Manifestations creating apparent authority] include explicit
statements that a principal makes directly to a third party, as well as statements made by others
concerning an actor's authority that reach the third party and are traceable to the principal.").
OvS has contended that Ms. Pinchuk's manifestations in prior interactions and the
contract negotiations led it to reasonably believe that Maypaul signed the Agreement with Ms.
Pinchuk's authority and on her behalf. See Opp., OvS's Mem. in Support of Prima Facie
Showing of Jurisdiction [ECF 10, Ex. 11] ("Prima Facie Mem.") at 11-13. In support of this
contention, OvS has cited, among other things: the fact that OvS submitted contract proposals to
hereby agree and confirm that [Maypaul] shall enter into agreements with third parties at its own
risk, and all rights and obligations shall be attached to [Maypaul]; [Transport Investments] shall
not be responsible for and bound by such agreements.").
20
the Pinchuks and made revisions based on Ms. Pinchuk's comments, see Mot. Vacate,
10/16/2006 Email [ECF 9, Ex. I] (letter proposal addressed to the Pinchuks); an email from one
of Ms. Pinchuk's representatives stating that Ms. Pinchuk was "studying" OvS's contract
proposal, Prima Facie Mem., Ex. 18; Aurika Dmitrieva's testimony that she and Ms. Pinchuk
"stud[ied] the conditions for payments and scope of work" in the Agreement, see Hearing Tr.
620-21, 666-67; and Lisa Delplace's testimony that Konstantin Ussar told her that Maypaul was
representing Ms. Pinchuk in signing the Agreement, see id. at 100, 150. See Prima Facie Mem.
at 12; Opp., OvS's Mem. in Support of Award [ECF 12, Ex. 12] at 14.
Ms. Pinchuk counters that "OvS could not reasonably believe that Maypaul acted for Mrs.
Pinchuk" because in the course of negotiating the Agreement, the parties' initial drafts
contemplated including the Pinchuks as signatories, later drafts contemplated just a corporate
entity as the signatory, and the email informing OvS that Maypaul would be the signatory made
no reference to the Pinchuks. See Mot. Vacate at 27-28; id., 2004-2006 Letter Proposals; id.,
1/15/2007 Draft Agreement; id., 2/2/2007 Email [ECF 9, Ex. T]. Therefore, Ms. Pinchuk argues,
OvS had no reason to believe that Maypaul was "signing the contract for the Pinchuks, rather
than as a substitute for them." Mot. Vacate at 27.
The Court concludes that OvS's perception that Maypaul entered into the Agreement on
Ms. Pinchuk's behalf was reasonable. See Sigal, 586 A.2d at 1219. Throughout the contract
negotiations, up until the day the Agreement was executed, OvS believed that it was negotiating
with the Pinchuks, that the project being negotiated was a residence for the Pinchuks, that the
contract was subject to Ms. Pinchuk's final approval, and hence that the Pinchuks would be
signing the contract. See Hearing Tr. at 95-99; 210. Though draft agreements left blanks for a
21
"legal entity" as a signatory, the blanks were part of a standard contract term, and as Lisa
Delplace explained, OvS "assum[ed] that [it] would be filling that out for the Pinchuks, since all
previous proposals had gone to them." Id. at 213. Then, according to Delplace, on the day the
Agreement was to be signed Konstantin Ussar told Delplace that Maypaul would sign it as Ms.
Pinchuk's representative. See id. at 150. In light of the Pinchuks' dealings with OvS to that date,
particularly the Pinchuks' means of communicating and negotiating through representatives, OvS
had good reason to think that the Pinchuks sought to contract through a representative, i.e.,
Maypaul, as well. Also, OvS believed that the Pinchuks owned the Property and that the
residence under construction was to be their home. See id. at 80, 142. Though the Pinchuks did
not in fact own the Property, no one corrected OvS's references to the project as the "Pinchuk
residence" or otherwise informed OvS that Svit Shylahiv owned the Property. See id. at 110,
610-11. And until the arbitration, OvS had no knowledge of either Ms. Pinchuk's preliminary
lease agreement with Svit Shylahiv or the agency agreement between Transport Investments and
Maypaul, both of which were "confidential." See Award at 17-18; Prelim. Lease ¶ 9.1;
Transport-Maypaul Agreement ¶ 6.2. It therefore made sense that OvS thought that the Pinchuks
were the "Owner" designated in the Agreement and that Maypaul was simply their agent.
The Court recognizes that there are facts in the record supporting Ms. Pinchuk's position.
This case is similar in some respects to Dorsky Hodgson & Partners, Inc. v. Nat'l Council of
Senior Citizens, 766 A.2d 54 (D.C. 2001), in which the D.C. Court of Appeals rejected an
architecture firm's argument that a corporation with which it had entered into a contract had
apparent authority to bind a senior citizens organization. There, the senior citizens organization
rather than the signatory corporation had begun the process to gain funding for the construction
22
project that was the subject of the contract, and the architecture firm had "repeated
communications" about the project with the organization's affiliate. Id. at 56. But these facts
"d[id] not change the reality" that the firm had contracted with the signatory corporation and
"repeatedly looked to [the corporation] for payment." See id. In addition, the contract as
originally drafted had been between the architecture firm and the organization's affiliate but, at
the affiliate's insistence, had been revised "to make explicit" that the corporation was retaining
the firm's services. Id. Similarly here, OvS signed a contract with Maypaul and was paid by
Maypaul, and the contract was revised to make Maypaul the signatory in place of the Pinchuks.
But this case is different from Dorsky Hodgson because circumstances not present in that
case "reasonably led [OvS] to believe" that Maypaul signed the Agreement as Ms. Pinchuk's
agent. See Dorsky Hodgson, 766 F.2d at 57. First, as discussed above, at the time the
Agreement was executed OvS was told that Maypaul was "representing" Ms. Pinchuk. See
Hearing Tr. at 100, 158. This did not "make explicit" that Maypaul, not Ms. Pinchuk, was
retaining OvS's services. See Dorsky Hodgson, 766 F.2d at 57. Moreover, OvS invoices were
addressed to and paid by Maypaul, but OvS actually sent its invoices to Interpipe, which was
Victor Pinchuk's company. See Hearing Tr. 55, 110-12, 159, 259. In fact, other than the address
below the signature line on the Agreement, OvS had no contact information for Maypaul, and, it
appears, did not communicate with anyone from Maypaul after signing the Agreement. See id. at
279-82. And other than initiating wire transfers to make payments, Maypaul undertook none of
the Agreement's rights and obligations; the Pinchuks or their representatives undertook these
rights and obligations instead. See Award at 23. In the Court's view, these facts substantiate the
reasonableness of OvS's belief that Maypaul had authority to enter into the Agreement for Ms.
23
Pinchuk. See Sigal, 586 A.2d at 1218-19.11
Based on Maypaul's apparent authority, Ms. Pinchuk was bound to arbitrate the present
dispute. Hence, the Court will deny Ms. Pinchuk's motion to vacate the arbitrator's Award
against her. See D.C. Code § 16-4423(a)(5).
II.
Merits
Maypaul argues that this Court should vacate the arbitrator's decision on the merits
because it manifestly disregarded District of Columbia law. See Mot. Vacate at 30.12 Before
turning to the specifics of Maypaul's arguments, the Court stresses that its review of the
arbitrator's decision is "extremely limited" and that Maypaul bears a "heavy burden." See Lopata,
735 A.2d at 940. To establish that the arbitrator "manifestly disregarded the law," Maypaul must
show "more than a mere error" of fact or law. See Fraternal Order of Police/Dep't of Corr. Labor
Comm. v. D.C. Pub. Emp. Relations Bd., 973 A.2d 174, 178 n.9 (D.C. 2009) (internal quotation
marks and citation omitted); Cathedral Ave. Coop., 947 A.2d at 1151 (court inquiry as to
"manifest disregard[]" may be undertaken, "at least when the decision approaches being arbitrary
and capricious") (internal quotation marks and citation omitted). Hence, even if the arbitrator
11
The Court does not adopt the requirement, urged by Ms. Pinchuk, that an alleged
principal and agent have a "pre-existing relationship" to support a finding of apparent authority.
See Mot. Vacate at 27-28 & n.3. Apparent authority depends not on an actual principal-agent
relationship, pre-existing or otherwise, but on the appearance of one. See Restatement (Third) of
Agency § 2.03 cmt. a ("The definition [of apparent authority] in this section does not presuppose
the present or prior existence of an agency relationship as defined in § 1.01.").
12
Because respondents' position is that the arbitrator did not have jurisdiction over Ms.
Pinchuk, respondents present their arguments on the merits as Maypaul's arguments. See Mot.
Vacate at 30-38. The Court treats them as such, but in light of the Court's conclusion that Ms.
Pinchuk was bound by the Agreement, its conclusions on the merits apply equally to Maypaul
and Ms. Pinchuk.
24
misapplied District of Columbia law, that would not be a basis for vacatur.
Maypaul first contends that the arbitrator manifestly disregarded the law in ruling that
Maypaul breached its contract with OvS. Mot. Vacate at 31. Maypaul asserts that the arbitrator
ignored District of Columbia law providing that an unambiguous and integrated contract, like the
Agreement here, "speaks for itself and binds the parties without the necessity of extrinsic
evidence." Mot. Vacate at 31 (citing, inter alia, Lumpkins v. CSL Locksmith, LLC, 911 A.2d
418, 423 (D.C. 2006)). But the arbitrator did not conclude that Maypaul breached the Agreement
as written. Rather, he concluded that the Agreement had been modified and that Maypaul and
Ms. Pinchuk breached the Agreement as modified. The cases cited by Maypaul do not address
contract modification and are therefore inapposite.
Maypaul also criticizes the arbitrator for relying "only" on the Uniform Commercial Code
("UCC") and District of Columbia jury instructions, arguing that the UCC would preclude oral
modification and the jury instruction on course of performance would preclude consideration of
extrinsic evidence in these circumstances. See Mot. Vacate at 32. But this is an argument that
the arbitrator misapplied the law, not that he manifestly disregarded it. Moreover, Maypaul
neglects to note that the arbitrator also cited District of Columbia authority on contract
interpretation that permits oral modification of a written contract even if the contract requires all
modifications to be in writing. See Award at 34, 36 (citing Nickel v. Scott, 59 A.2d 206, 207
(D.C. 1948); D.C. Standardized Civil Jury Instruction § 11-23 ("Even if the written contract itself
requires that all modifications to it must be in writing, the law permits the parties to modify a
written contract by a later oral agreement.")); see also Puma v. Sullivan, 746 A.2d 871, 875 (D.C.
2000) ("[U]nder contract law, it is well-settled that a written contract may be modified or
25
rescinded by a subsequent oral agreement, even where the contract contains express language
prohibiting oral modification[.]" (citing Nickel, 59 A.2d at 207)).
Maypaul finally challenges the arbitrator's factual finding that Maypaul agreed to an oral
modification of the Agreement. See Mot. Vacate at 33-34. But to repeat, an error of fact does
not amount to manifest disregard of the law, and the arbitrator amply supported his finding that
the Agreement was modified in scope and duration by citing specific evidence in the record. See
Award at 37-40 (describing, for example, a May 2008 "revised proposal for the additional scope
of work through May 2009"; "[c]hanges to a road location and elimination of a wall, just one
week before the Contract work was purportedly to be completed"; the June 2008 approval of an
electronic entry gate with "significant modifications"; the parties' August 2008 exchange of
comments on a draft addendum to the Agreement; and Lisa Delplace's trips to Kiev in the
summer and fall of 2008 at the request of Ms. Pinchuk and her representatives); id. at 39
("[N]either Maypaul nor Ms. Pinchuk could reasonably have expected that OvS would do this
work after July 1 without compensation or reimbursement of out-of-pocket expenses."). Hence,
the Court concludes that the arbitrator did not manifestly disregard the law in ruling that Maypaul
and Ms. Pinchuk breached the Agreement as modified.
In light of this conclusion, the Court need not address the arbitrator's alternative holding
that Maypaul and Ms. Pinchuk were liable in quantum meruit. The dollar amount of professional
services provided and expenses incurred is the same in damages as in restitution.
Maypaul also contends that the arbitrator manifestly disregarded the law in awarding OvS
reimbursable expenses, prejudgment interest, and attorney's fees and costs. First, Maypaul
claims that the arbitrator ignored the Agreement's cap on monthly reimbursable expenses at 40%
26
of monthly professional fees, or $8,952, and argues that the award of $76,270.49 in reimbursable
expenses should be reduced to that amount. Mot. Vacate at 36. But far from ignoring the 40%
cap, the arbitrator reasoned that "throughout the duration of the Contract OvS was regularly
reimbursed for expenditures without regard to the 40% limit [in the Agreement] and without
approval from Maypaul" and, accordingly, concluded that "Maypaul acquiesced without
objection to waivers and modifications of the Contract by Ms. Pinchuk and her representatives
that overrode any limit in the Contract on reimbursable expenditures [or other requirements]."
Award at 41. This was not manifest disregard of the law.
Second, Maypaul argues that in awarding prejudgment interest at 18% per annum, the
arbitrator ignored District of Columbia law capping prejudgment interest at 6% per annum. Mot.
Vacate at 36. In District of Columbia v. Pierce Associates, cited by Maypaul, the D.C. Court of
Appeals held that a trial court may not award prejudgment interest at a rate greater than 6%,
"unless an express contractual provision is to the contrary." 527 A.2d 306, 311 (D.C. 1987). But
in Maypaul's own words, the arbitrator awarded OvS prejudgment interest "at the contract rate of
18% per annum." Mot. Vacate at 36 (emphasis added). It would seem that paragraph 6.2 of the
Agreement setting an interest rate of 18% per annum on past due payments is "contrary" to a 6%
rate. And even if the arbitrator erred, he did not manifestly disregard the law because he
considered that both parties sought prejudgment interest at the contract rate and stated his
authority to award interest under the AAA Construction Rules. Award at 47.
Finally, Maypaul argues that the Court should vacate in part the award of attorney's fees
and costs to OvS because the arbitrator "effectively granted Maypaul's counterclaim for breach of
contract." Mot. Vacate 37. But Maypaul cites no law that was manifestly disregarded. The
27
arbitrator denied Maypaul's counterclaim and, pursuant to his authority under the AAA
Construction Rules, see R-45(d)(ii), awarded reasonable attorney's fees and costs to OvS as the
prevailing party in the arbitration. See Award at 48-49, 53. The Court will not disturb the
Award on this basis.
Maypaul has not met its "heavy burden" of showing manifest disregard of the law. See
Lopata, 735 A.2d at 940. Accordingly, the Court will deny the motion to vacate and confirm the
Award against Maypaul and Ms. Pinchuk in its entirety. See D.C. Code § 16-4423(e).
CONCLUSION
For the foregoing reasons, OvS's motion for confirmation of the Award will be granted,
and respondents' motion to vacate the Award will be denied. The Award will be confirmed in its
entirety. A separate order accompanies this opinion.
/s/
JOHN D. BATES
United States District Judge
Dated: November 6, 2012
28
Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.
Why Is My Information Online?