ADA-ES, Inc. v. Big Rivers Electric Corporation
Filing
77
MEMORANDUM OPINION AND ORDER Signed by Judge Joseph H. McKinley, Jr. on 1/24/2019: The Plaintiff's Motion 59 for Partial Summary Judgment is DENIED; Defendant's Cross-Motion 63 for Partial Summary Judgment is GRANTED; The Defendant's Rule 56(d) Motion 63 is GRANTED; Plaintiff's Motion 66 to Strike is DENIED. cc: Counsel(JM)
UNITED STATES DISTRICT COURT
WESTERN DISTRICT OF KENTUCKY
OWENSBORO DIVISION
CIVIL ACTION NO: 4:18-CV-00016-JHM
ADA-ES, INC.
PLAINTIFF
V.
BIG RIVERS ELECTRIC
CORPORATION
DEFENDANT
MEMORANDUM OPINION AND ORDER
This matter is before the Court on Plaintiff’s Motion for Partial Summary Judgment [DN
59], Defendant’s Cross-Motion for Partial Summary Judgment [DN 63], Defendant’s Rule 56(d)
Motion [DN63], and Plaintiff’s Motion to Strike the Sur-Reply Portions of Defendant’s Reply
[DN 66]. Fully briefed, these matters are ripe for decision. For the following reasons, Plaintiff’s
Motion for Partial Summary Judgment is DENIED, Defendant’s Cross-Motion for Partial
Summary Judgment is GRANTED, Defendant’s Rule 56(d) Motion is GRANTED, and
Plaintiff’s Motion to Strike is DENIED.
I.
BACKGROUND
According to the Complaint, Plaintiff ADA-ES, Inc. (“ADA-ES”) contracted with Big
Rivers Electric Corporation (“Big Rivers”) for the engineering, manufacturing, and delivery of
equipment and materials for a Dry Sorbent Injection System (“DSI System”). [DN 20 ¶ 7].
Pursuant to a requirement of the Request for Quotes (“RFQ”), ADA-ES posted an irrevocable
standby letter of credit in the amount of $807,651.00 through CoBiz Bank in Denver, Colorado,
to serve as security for performance under the contract. [Id. ¶ 11]. In accordance with the contract,
ADA-ES engineered, manufactured, and delivered a DSI System, which was incorporated into a
power plant owned by Big Rivers. [Id. ¶ 13]. The purpose of the system was to inject a powdered
sorbent into the power plant system where exhaust gas is produced to bind with, capture, and
sequester the pollutant, Sulfur Trioxide gas (“SO3”), created from the burning of fuel. [Id.]. In
other words, the DSI System was to be used to reduce SO3 emissions to a specific level. [Id.].
According to the contract documents—the RFQ, the contract, and the purchase order [DN
63-1 ¶ 17]—“Performance Guarantee Test Procedures” were to be mutually agreed upon and
provided by ADA-ES 75 days after notice to proceed was granted by Big Rivers. [DN 20 ¶¶ 14–
15]. These procedures were to provide guidelines for Big Rivers’ testing of the DSI System after
delivery and installation. On or about January 8, 2016, ADA-ES provided Big Rivers with the
DSI Performance Test Procedure. [DN 20-7]. Those guidelines were incorporated into the final
protocol for the test program, named CleanAir Protocol. [DN 20-8, 9, 10].
In March 2016, after the DSI System was installed and the performance test guidelines
were finalized, Big Rivers conducted its first performance test on the DSI System. [DN 20 ¶ 19].
Big Rivers claimed the system failed the test by failing to reduce the amount of SO3 emissions to
less than five parts per million (ppm)—the contractually agreed upon reduction—when a specified
amount of sorbent was consumed under specified conditions. [Id. ¶ 20]. Thereafter, Big Rivers
notified ADA-ES of the failed test. ADA-ES responded that “it disagreed with Big Rivers’
conclusions about the test, and informed Big Rivers that the way to cure the alleged problem was
to use the High Reactivity Hydrated Lime as called for in the Test Procedures and the CleanAir
Protocol.” [Id. ¶ 22]. Big Rivers conducted a second test in June 2016 using a sorbent it claimed
satisfied the contract’s requirement and informed ADA-ES that the system again failed the
performance test. [Id. ¶ 23].
Based on the failed performance tests, Big Rivers issued a claim for damages in the amount
of $605,458.78, “which constituted its quantification of damages and asserted a right to both actual
2
and liquidated damages for the same alleged performance breach.” [Id. ¶ 24]. Big Rivers
thereafter withheld $563,382.56 of contract payments. Additionally, Big Rivers withdrew the
entire $807,651.00 letter of credit funds, using the same basis it used to justify the withheld
contract payments. [Id. ¶ 27].
On May 11, 2017, ADA-ES filed an Amended Complaint alleging Fraud (Count I), Unjust
Enrichment (Count II), Breach of UCC Warranties (Count IV), Breach of Contract (Count V), and
seeking Declaratory Judgment as to seven claims (Count III). [DN 20 ¶¶ 35–77]. In July 2018,
ADA-ES filed the instant Motion for Partial Summary Judgment requesting that this Court grant
declaratory judgment in its favor as to two of the seven claims—the contractually-permissible
damages and the contractually-required sorbent to be used in the DSI System. [DN 59 at 1]. Big
Rivers responded opposing ADA-ES’s Motion as to both claims, filing its own Motion for Partial
Summary Judgment as to the contractually-permissible damages, and filing a Rule 56(d) Motion
asking the Court to deny or defer ruling on ADA-ES’s Motion as it pertains to the
contractually-required sorbent until further discovery could be conducted. [DN 63]. ADA-ES
filed in a single document its Reply in support of its initial Motion for Partial Summary Judgment,
a Response to Big Rivers’ Cross-Motion for Partial Summary Judgment, and its Response in
opposition to Big Rivers’ Rule 56(d) Motion. [DN 64]. In what would have been the final filing,
Big Rivers filed its Reply in support of its Cross-Motion for Partial Summary Judgment and its
Rule 56(d) Motion. [DN 65]. However, ADA-ES took issue with the substantive arguments made
by Big Rivers’ in its Reply. Accordingly, ADA-ES filed a Motion to Strike the portions of Big
Rivers’ Reply that, in its opinion, constituted a sur-reply. [DN 66]. Big Rivers responded that its
Reply consisted only of appropriate arguments and, as such, requested that the Court deny the
3
drastic remedy sought by ADA-ES in its Motion to Strike. [DN 67]. The final brief in this long
saga was filed November 9, 2018—ADA-ES’s Reply in support of its Motion to Strike. [DN 69].
II.
STANDARD OF REVIEW AND LAW
Before the Court may grant a motion for summary judgment, it must find that there is no
genuine dispute as to any material fact and that the moving party is entitled to judgment as a matter
of law. Fed. R. Civ. P. 56(a). The moving party bears the initial burden of specifying the basis
for its motion and identifying the portion of the record that demonstrates the absence of a genuine
issue of material fact. Celotex Corp. v. Catrett, 477 U.S. 317, 322 (1986). Once the moving party
satisfies this burden, the non-moving party thereafter must produce specific facts demonstrating
a genuine issue of fact for trial. Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 247–48 (1986).
Although the Court must review the evidence in the light most favorable to the
non-moving party, the non-moving party must do more than merely show that there is some
“metaphysical doubt as to the material facts.” Matsushita Elec. Indus. Co., Ltd. v. Zenith Radio
Corp., 475 U.S. 574, 586 (1986). Instead, the Federal Rules of Civil Procedure require the
non-moving party to present specific facts showing that a genuine factual issue exists by “citing
to particular parts of materials in the record” or by “showing that the materials cited do not
establish the absence . . . of a genuine dispute[.]” Fed. R. Civ. P. 56(c)(1). “The mere existence
of a scintilla of evidence in support of the [non-moving party’s] position will be insufficient; there
must be evidence on which the jury could reasonably find for the [non-moving party].” Anderson,
477 U.S. at 252.
III.
DISCUSSION
The Court will address first the Motion to Strike followed by the motions regarding partial
summary judgment.
4
A. ADA-ES’s Motion to Strike Sur-Reply [DN 66]
Following Big Rivers’ Reply pertaining to its Cross-Motion for Partial Summary
Judgment and its Rule 56(d) Motion, ADA-ES filed a Motion to Strike the Sur-Reply Portions of
that Reply. [DN 66]. ADA-ES contends that Big Rivers improperly asserted substantive
arguments regarding whether the contract required high reactivity hydrated lime for performance
testing in its Reply. [Id. at 1]. Specifically, ADA-ES argues that Big Rivers disguised substantive
arguments as a Rule 56(d) Reply which instead should be used to show the Court why additional
discovery is necessary prior to a summary judgment ruling—“a blatant effort to get the last word
on ADA-ES’s motion that had already been fully briefed.” [Id. at 3–4]. ADA-ES requests that
the Court strike the sur-reply portions of Big Rivers’ Reply or, in alternative, allow oral argument
on ADA-ES’s Motion for Partial Summary Judgment. [Id. at 4]. Big Rivers responded that its
Reply was clearly related to its Rule 56(d) Motion, specifically discussing the need for additional
discovery on the type of lime sorbent to be used in the performance tests of the DSI System. [DN
67 at 3–7].
ADA-ES retorts that Big Rivers’ Reply argued why it believed the contract
unambiguously warrants a decision in its favor, an impermissible argument for a Rule 56(d) filing.
[DN 69 at 1].
Big Rivers correctly notes that Rule 12(f) of the Federal Rules of Civil Procedure governs
motions to strike pleadings. That Rule provides that “[t]he court may strike from a pleading any
insufficient defense or any redundant, immaterial, impertinent, or scandalous matter.” Fed. R.
Civ. P. 12(f). “Motions to strike under Rule 12(f) are addressed within the sound discretion of
the Court, although they are generally disfavored.” Hashemian v. Louisville Reg'l Airport Auth.,
No. 3:09-CV-951, 2013 WL 1788473, at *5 (W.D. Ky. Apr. 26, 2013) (citing Ameriwood Indus.
Intern. Corp. v. Arthur Andersen & Co., 961 F. Supp. 1078, 1083 (W.D. Mich. 1997) (internal
5
citations omitted)). “Striking a pleading is a drastic remedy to be resorted to only when required
for the purposes of justice.” Id. (citing Brown & Williamson Tobacco Corp. v. United States, 201
F. 2d 819, 822 (6th Cir. 1953)). In this case, such a remedy is improper.
ADA-ES repeatedly mischaracterizes Big Rivers’ Reply as containing new arguments.
Specifically, ADA-ES takes issue with Big Rivers’ argument concerning the sorbent used being
in conformance with the specifications of the contract and the contention that the contract did not
require a specific sorbent or sorbent provider for performance testing. [DN 66 at 3]. Both
arguments appear in Big Rivers’ initial Rule 56(d) Motion. [DN 63 at 4, 21]. Further, in its initial
Motion, Big Rivers explains that it believes the evidence developed with additional discovery will
show that “the parties’ agreement contemplated the use of hydrated lime meeting specifications
of the Contract” and that it used hydrated lime meeting those specifications during the
performance testing. [Id. at 19–21; DN 63-1 ¶¶ 39–40]. Accordingly, ADA-ES had ample
opportunity to respond to this argument and its use in the Reply is not new or prejudicial. As for
Big Rivers’ statements concerning the contract not requiring a specific sorbent or sorbent
provider, it argues that it was necessary in order to explain how the phrase “high reactivity
hydrated lime” remains ambiguous outside the context of a specific provider’s line of products.
[DN 67 at 6]. That argument’s connection to a Rule 56(d) reply in this case is not evident to the
Court. However, this line of argument was first raised in Big Rivers’ initial motion [DN 63 at 4].
Consequently, ADA-ES is not prejudiced by its later inclusion in Big Rivers’ Rule 56(d) reply
and the striking of that argument is unnecessary.
Finally, and more broadly, ADA-ES takes issue with Big Rivers’ framing its Reply in
terms of why summary judgment is precluded. [DN 66 at 3]. However, Big Rivers correctly
points out that such a framing is a prerequisite to showing why summary judgment is premature
6
and further discovery is warranted under Rule 56(d). [DN 67 at 6]. Additionally, because this
same argument was clearly outlined in Big Rivers’ initial Motion, ADA-ES is not prejudiced by
the Reply and the Motion to Strike is unwarranted. Accordingly, ADA-ES’s Motion to Strike is
DENIED.
B. Motions for Partial Summary Judgment
Having denied ADA-ES’s Motion to Strike, the Court can now address the motions for
partial summary judgment.
1. Permissible Damages
Regarding recoverable damages under the contract, both parties seek partial summary
judgment in their favor. [DN 59; DN 63]. ADA-ES claims that “the Contract unambiguously
provides that liquidated damages capped at 10% of the Contract value is the exclusive remedy for
a proven performance-based breach of the Contract.” [DN 59 at 6]. That being the case, ADA-ES
claims entitlement to summary judgment on its claim for declaratory relief that Big Rivers’
“recovery for any purported performance-based breach of Contract is limited to liquidated
damages capped at 10% of the Contract value.” [Id.]. Big Rivers not only responded in opposition
to ADA-ES’s Motion, but it filed a Cross-Motion for Partial Summary Judgment concerning the
same matter. [DN 63]. Therein, Big Rivers explained that the liquidated damages clause of the
contract did not apply to the breach at issue in this case—a “make good” guarantee. [Id. at 9–12].
Accordingly, Big Rivers requested that this Court “deny ADA[-ES’s] motion on this issue and,
instead, grant Big Rivers’ cross-motion for summary judgment.” [Id. at 12].
The issues raised in both parties’ motions for partial summary judgment are governed by
principles of contract interpretation, a matter of state law. Under Kentucky law, “the construction
and interpretation of a contract including questions regarding ambiguity are questions of law to
7
be decided by the Court[.]” Hulda Schoening Family Trust v. Powertel/Kentucky Inc., 275 F.
Supp. 2d 793, 794 (W.D. Ky. 2003) (citation omitted). “In construing a contract, a court’s primary
objective is to ascertain and to effectuate the intention of the parties to the contract from the
contract itself.” Logan Fabricom, Inc. v. AOP P’ship LLP, No. 2004-CA-002410, 2006 WL
3759412, at *2 (Ky. App. Dec. 22, 2006). A court’s analysis thus begins with a contract’s four
corners. See 3D Enters. Contracting Corp. v. Louisville & Jefferson Cnty. Metro. Sewer Dist.,
174 S.W.3d 440 (Ky. 2005) (noting that when no ambiguity in a contract exists, a court should
look “only as far as the four corners of the document to determine the parties’ intentions”). As a
rule, a contract “must be construed as a whole, giving effect to all parts and every word in it if
possible.” Am. Dairy Queen Corp. v. Fortune St. Research & Writing Inc., 753 F. Supp. 2d 675,
679 (W.D. Ky. 2010) (citation omitted).
“‘[I]n the absence of ambiguity a written instrument will be enforced strictly according to
its terms,’ and a court will interpret the contract’s terms by assigning language its ordinary
meaning and without resort to extrinsic evidence.” Frear v. P.T.A. Indus., Inc., 103 S.W.3d 99,
106 (Ky. 2003) (quoting O’Bryan v. Massey-Ferguson, Inc., Ky., 413 S.W.2d 891, 893 (Ky.
1966)). If a contract is ambiguous, however, a court may “consider parol and extrinsic evidence
involving the circumstances surrounding execution of the contract, the subject matter of the
contract, the objects to be accomplished, and the conduct of the parties[.]” Wolf River Oil Co. v.
Equity Grp.-Ky. Div., LLC, No. 1:09-CV-00030, 2010 WL 427775, at *2 (W.D. Ky. Feb. 3, 2010)
(quoting Cantrell Supply, Inc. v. Liberty Mut. Ins. Co., 94 S.W.3d 381, 385 (Ky. App. 2002)).
The fact that the parties disagree about a contract’s interpretation does not mean that it is
ambiguous. See B.F. Goodrich Co. v. U.S. Filter Corp., 245 F.3d 587, 594 (6th Cir. 2001) (noting
that “disputed issues of contractual interpretation can be resolved at summary judgment on the
8
basis that they are questions of law”); see also Cantrell Supply, Inc., 94 S.W.3d at 385 (stating
that “[t]he fact that one party may have intended different results . . . is insufficient to construe a
contract at variance with its plain and unambiguous terms”). Instead, a contract is ambiguous
only “if it can be reasonably interpreted to support two different positions.” Albert M. Higley Co.
v. N/S Corp., 445 F.3d 861, 865 (6th Cir. 2006). Once a court determines that a contract is
ambiguous, “areas of dispute concerning the extrinsic evidence are factual issues” and contract
construction becomes “subject to resolution by the fact-finder.” Rite Aid of Ky., Inc. v. Foursome
Props., LLC, No. 2010-CA-001199, 2011 WL 3516851, at *2 (Ky. App. Aug. 12, 2011).
Importantly, documents that are executed at the same time and concern the same subject
matter should be read and construed together to ascertain the parties’ intent. See, e.g.,
ABCO-BRAMER, Inc. v. Markel Ins. Co., 55 S.W.3d 841 (Ky. Ct. App. 2001) (contracts must be
construed as a whole and all writings that are part of the same agreement must be construed
together); Veech v. Deposit Bank of Shelbyville, 278 Ky. 542 (Ct. App. 1939) (instruments that
are part of the same transaction may be interpreted together in determining the parties’ intent). In
the present case, the parties’ RFQ and contract concern the same subject matter and were executed
by the parties in respective sittings. Also, the RFQ refers to the contract and vice versa. Therefore,
they must be construed together. Additionally, the RFQ and contract expressly call for the
creation of the Performance Test Procedures and CleanAir Protocol.
Accordingly, those
documents will also be construed together.
The relevant sections of the contract documents for a damages cap include both portions
of the RFQ and the contract itself—§§ 1.22 and 7.1 as well as the Limitation Liability Provision
of the RFQ and § 492000 of the contract. As previously mentioned, a contract is ambiguous only
“if it can be reasonably interpreted to support two different positions.” Albert M. Higley Co. v.
9
N/S Corp., 445 F.3d 861, 865 (6th Cir. 2006). As a rule, conflicting clauses should be construed
to harmonize with each other if harmonization can consistently and reasonably be done. 17A Am.
Jur. 2d Contracts § 384; see Int’l Union of Op. Eng. v. J.A. Jones Constr. Co., 240 S.W.2d 49, 56
(Ky. 1951). In this case, reading the relevant clauses together warrants a conclusion that the
contract unambiguously provides no damages cap to the breach of contract claimed by Big Rivers.
The Court looks first at the provisions in the RFQ. The RFQ contains a definitions section
which defines “Liquidated Damages” as “payments which the Contractor shall make to the Owner
for the value of damages experienced by the Owner to compensate for additional operational
experiences or missed delivery schedules defined within the Contract.” [DN 59-3 § 1.22]. The
next provision, found in the “Commercial Terms” section, is the provision relied upon by
ADA-ES. Section 7.1 provides:
Performance based Liquidated Damages will be calculated from the Bidder’s
submittal referenced in Section 492000 of the Engineer’s Technical Specification.
The following values will be the basis for final Liquidated Damages:
a. Hydrated Lime: $10,000 per pound per hour
b. Power Consumption: $8,600 per kilowatt hour
Contractor’s total liability for Performance based Liquidated Damages will be
capped at 10% of the total Contract value. Performance based Liquidated
Damages will be Owner’s sole and exclusive remedy for Contractor’s failure to
meet performance guarantees.
[Id. § 7.1]. The final provision of the RFQ relevant to this inquiry concerns limitations on liability.
Specifically, it provides:
In no event will Contractor’s liability to the Company for any and all claims,
including property damages and personal injury claims, liquidated damages, make
right work, and any other claims of any sort allegedly resulting from breach of
contract, tort, or any other theory of liability exceed the amount of the initial
purchase price paid to the Contractor for the Work giving rise to the claim.
[Id. at 39].
10
Now the Court turns its attention to the remaining relevant provision in the contract.
Section 492000 provides information concerning “Performance Guarantees” of the DSI System.
[DN 59-2 § 492000].
Importantly, the provision distinguishes between “Make Good”
performance guarantees and DSI system guarantees which are subject to liquidated damages.
[Id.]. The provision provides:
1. The following DSI system guarantees are ‘Make Good’ performance
guarantees:
a. Maximum SO3 Emission Rate at air preheater outlet, ppm: 5.0 . . .
2. The following DSI System Guarantees are subject to Liquidated Damages. . . .
(1) Hydrated lime consumption at Performance conditions, lb/hr:
2,475
[Id.]. Having laid out the relevant provisions, the Court can now address the reasonableness of
the respective interpretations.
ADA-ES relies heavily on the commercial terms section of the RFQ, even more
specifically on the text that provides “[c]ontractor’s total lability for Performance based
Liquidated Damages will be capped at 10% of the total Contract value. Performance based
Liquidated Damages will be Owner’s sole and exclusive remedy for Contractor’s failure to meet
performance guarantees.” [DN 59-3 § 7.1]. Reading this provision without the context of the
remaining provisions could lead a Court to the conclusion that the damages Big Rivers’ sought
were to be limited to ten percent of the contract value. However, such a reading is not in line with
the principles of contract interpretation cited above. Instead, this provision must be read in
conjunction with, and in the context of, the remaining relevant provisions. Doing so, reveals that
ADA-ES’s interpretation is unreasonable.
Section 492000 of the Contract makes clear that “make good” performance guarantees are
distinct from those system guarantees that are subject to liquidated damages. [DN 59-2 § 492000].
This distinction is only made more evident after reading the definition of liquidated damages
11
included in the RFQ. [59-3 § 1.22]. That provision specifies that liquidated damages are those
payments made by the Contractor to the Owner for additional operational expenses—for example,
additional pounds of hydrated lime needed per hour to allow the DSI System to function properly.
[Id.]. The failure to create a system that reduces SO3 emissions, the breach alleged by Big Rivers,
does not qualify as “additional operational expenses” under any reasonable interpretation. The
proverbial nail in the coffin of ADA-ES’s asserted interpretation comes with the limitations on
liability provision of the RFQ. [Id. at 39]. That section clearly distinguishes between liquidated
damages claims and make right work claims when limiting the Contractor’s total liability. [Id.].
Reading these provisions in conjunction with the commercial terms section relied upon by
ADA-ES convinces the Court that ADA-ES’s interpretation is unreasonable. Instead, Big Rivers’
offered interpretation, that the contract contains no damages cap for the breach of a “make good”
guarantee, is the only reasonable interpretation.
Because a fact-finder could not reasonably find for ADA-ES, summary judgment is
appropriate in favor of Big Rivers. Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 252 (1986).
ADA-ES’s motion for partial summary judgment as to contractually-authorized damages for the
alleged failure to produce an adequate DSI System is DENIED and Big Rivers’ motion on the
same matter is GRANTED.
2. Lime Quality
The final issue before the Court is whether ADA-ES is entitled to partial summary
judgment on the issue of the quality of lime required by contract for the DSI System performance
tests. The same principles of contract interpretation outlined above apply here. ADA-ES filed a
Motion for Partial Summary Judgment requesting a declaration that the Contract required the use
of high reactivity hydrated lime for the performance tests, and, because Big Rivers failed to use
12
high reactivity hydrated lime, it breached the contract. [DN 59 at 7–8]. Big Rivers responded
disputing that it did not use the quality of lime specified in the contract, thus requesting that the
Court deny ADA-ES’s Motion. [DN 63 at 12–16]. In the alternative, Big Rivers moved, pursuant
to Rule 56(d), for the Court to deny or defer ruling on the issue to allow further discovery. [Id. at
16–25].
As previously stated, where the terms of the contract are unambiguous, “[t]he construction,
meaning, and legal effect of [the] contract is a matter of law for the court to decide . . . .” Siemens
Bldg. Techs., Inc. v. BTS, Inc., No. 00-688, 2002 WL 32097057, at *2 (W.D. Ky. Feb 1, 2002).
A contract is ambiguous only “if it can be reasonably interpreted to support two different
positions.” Albert M. Higley Co. v. N/S Corp., 445 F.3d 861, 865 (6th Cir. 2006). Regarding the
provisions concerning the quality of hydrated lime to be used in the DSI System, it is evident that
a conflict exists. The documents—the RFQ, the contract, the Performance Test Procedures, and
the CleanAir Protocol—refer to hydrated lime, hydrated lime with specific enumerated
characteristics, “enhanced” hydrated lime, and “high reactivity” hydrated lime as the required
sorbent. The latter two terms are never defined by those documents. Therein lies the conflict.
Thus far, extrinsic evidence has not been submitted to aid the Court’s interpretation of the
contract. Big Rivers explains that the lack of extrinsic evidence is due to the filing of this Motion
prematurely, before discovery can be conducted. That being the case, Big Rivers asks the Court
to deny or defer ruling on ADA-ES’s Motion pursuant to Rule 56(d) of the Federal Rules of Civil
Procedure. That rule provides that if a non-movant “shows by affidavit or declaration that, for
specified reasons, it cannot present facts essential to justify its opposition, the court may: (1) defer
considering the motion or deny it; (2) allow time to obtain affidavits or declarations or to take
discover; or (3) issue any other appropriate order.” Fed. R. Civ. P. 56(d). “The burden is on the
13
party seeking additional discovery to demonstrate why such discovery is necessary.” Summers v.
Leis, 368 F.3d 881, 887 (6th Cir. 2004) (citing Wallin v. Norman, 317 F.3d 558, 564 (6th Cir.
2003)). “Bare allegations or vague assertions of the need for discovery are not enough.” Id. at
887 (citation omitted). “In order to fulfill the requirements of Fed. R. Civ. P. 56[(d)], [a
non-moving party] must state with ‘some precision the materials [it] hopes to obtain with further
discovery, and exactly how [it] expects those materials would help [it] in opposing summary
judgment.’” Id. (quoting Simmons Oil Corp. v. Tesoro Petroleum Corp., 86 F.3d 1138, 1144 (Fed.
Cir. 1996)); Sharkey v. FDA, 250 Fed. App'x 284, 291 (11th Cir. 2007) (internal quotation marks
omitted) (“A Rule 56[(d)] motion must be supported by an affidavit which sets forth with
particularity the facts the moving party expects to discover and how those facts would create a
genuine issue of material fact precluding summary judgment.”).
Big Rivers submits an affidavit which adequately demonstrates the need for additional
discovery. Big Rivers, through affiant Robert Toerne, claims additional discovery will allow it
an opportunity to develop several lines of evidence. [DN 63-1 ¶¶ 37–41]. Specifically, evidence
regarding ADA-ES’s internal understanding regarding the agreed upon sorbent, evidence that the
term “highly reactive” was written out or subsumed by the contract, and evidence concerning the
industry and trade usage of the relevant terms. [Id.]. Big Rivers explains that this additional
evidence would help it prove that the parties mutually agreed that hydrated lime with specific
enumerated characteristics, not “high reactivity” hydrated lime, would be used in the DSI System.
It is well-settled in the Sixth Circuit that “when the parties have no opportunity for
discovery . . . ruling on a summary judgment motion is likely to be an abuse of discretion.”
CenTra, Inc. v. Estrin, 538 F.3d 402, 420 (6th Cir. 2008) (citing Ball v. Union Carbide Corp., 385
F.3d 713, 719 (6th Cir. 2004)). As such, Big Rivers’ Rule 56(d) Motion is GRANTED and
14
ADA-ES’s Motion for Partial Summary Judgment as to the required sorbent is DENIED without
prejudice.
IV.
CONCLUSION
For the reasons set forth above, IT IS HEREBY ORDERED as follows:
(1) The Plaintiff’s Motion for Partial Summary Judgment is DENIED;
(2) The Defendant’s Cross-Motion for Partial Summary Judgment is GRANTED;
(3) The Defendant’s Rule 56(d) Motion is GRANTED;
(4) and the Plaintiff’s Motion to Strike is DENIED.
January 24, 2019
cc: counsel of record
15
Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.
Why Is My Information Online?