American Municipal Power, Inc. v. Voith Hydro, Inc.
Filing
420
OPINION AND ORDER granting 257 Motion for Partial Summary Judgment; denying 258 Motion for Partial Summary Judgment; denying 259 Motion for Partial Summary Judgment; granting 260 Motion for Partial Summary Judgment; denying 262 Motion for Partial Summary Judgment; denying 263 Motion for Partial Summary Judgment; granting in part and denying in part 275 Motion for Partial Summary Judgment. Signed by Chief Judge Algenon L. Marbley on 10/19/2022. (cw)
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 1 of 56 PAGEID #: 63358
IN THE UNITED STATES DISTRICT COURT
FOR THE SOUTHERN DISTRICT OF OHIO
EASTERN DIVISION
AMERICAN MUNICIPAL POWER, INC.
Plaintiff,
v.
VOITH HYDRO, INC.,
Defendant.
:
:
: Case No. 2:17-cv-00708-ALM-EPD
:
: CHIEF JUDGE ALGENON L. MARBLEY
:
: MAGISTRATE JUDGE DEAVERS
:
:
OPINION & ORDER
This matter comes before the Court on Defendant’s six Motions for Partial Summary
Judgment (ECF Nos. 257, 258, 259, 260, 262, and 263). In addition to providing responses to the
Defendant’s several motions, Plaintiff filed its Motion for Partial Summary Judgment (ECF No.
275). Parties were heard on their opposing motions on Monday, September 12, 2022. Defendant’s
First and Fourth Motions for Partial Summary Judgment (ECF no. 257, 260) is GRANTED, while
Defendant’s Second, Third, Fifth, and Sixth Motions for Partial Summary Judgment (ECF Nos.
258, 259, 262, and 263) are DENIED. Plaintiff’s Motion for Summary Judgment (ECF No. 275)
is GRANTED in part and DENIED in part.
I.
BACKGROUND
A. Factual Background
This matter is a diversity lawsuit stemming from a contract dispute between Plaintiff
American Municipal Power, Inc. (“AMP”) and Defendant Voith Hydro, Inc. (“Voith”). AMP is a
wholesale power supplier that started building four hydroelectric power plants along the Ohio
River in the mid-2000s. (ECF No. 275 at 17–18). The power plants are as follows—one at the
1
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 2 of 56 PAGEID #: 63359
Cannelton Locks and Dam near Hawesville, Kentucky (“Cannelton”); one at the Smithland Locks
and Dam near Smithland, Kentucky (“Smithland”); one at the Captain Anthony Meldahl Locks
and Dam near Foster, Kentucky (“Meldahl”); and one at the Willow Island Locks and Dam near
New Martinsville, West Virginia (“Willow Island”). (Id. at 18). The instant litigation arises from
the design and construction of these Projects, centered primarily around the Cannelton Project.
Voith is a self-described “global supplier of hydroelectric equipment, technology and
services” that “designs, manufactures and supplies hydropower equipment and services for
hydropower plants around the world.” (ECF No. 32-1 ¶ 3). AMP hired Defendant Voith in 2007
to design, manufacture, and supply the required equipment (including turbines, governing system,
and generators) and associated services (such as submitting technical drawings and other
information for proper installation) for all four Projects. (ECF No. 275 at 18). AMP also hired
MWH Americas, Inc., (“MWH”) to serve as the Engineer of Record on the Projects. (Id.) AMP
entered into four contracts—one for each Project—with a contractor (“Installation Contractor”)
responsible for building the power plants into which Voith’s turbine and generator equipment
would be installed and for providing the labor to install the equipment consistent with Voith’s
instruction and oversight. (Id.)
The contracts for Cannelton, Smithland, and Willow Island were executed on June 6, 2008,
and the contract for Meldahl was executed on March 12, 2009 (collectively, the “Contracts”). (ECF
No. 240 ¶¶ 1–2). Each contract contained the same material provisions. The Contracts had a
combined initial Contract Price totaling approximately $415 million. (Id.). The figure for the
current approved Contract Prices stands at nearly $442 million after accounting for various
adjustments in the Contracts. (Id. ¶ 3). AMP has paid Voith the value of the current approved
Contract Price minus $33,017,353, which it has withheld subject to the Court’s future
2
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 3 of 56 PAGEID #: 63360
determination in this case. (Id. ¶ 5). On March 11, 2022, the parties jointly stipulated that the
Contractor Liability Limits (set out in Articles 5.2.1, 5.2.2 and 5.2.3 of the Contracts) and the
Owner Liability Limits (set out in Article 5.1.1 of the same) of the Contracts will apply without
exception to the Parties’ damage claims, such that the Contractual Price Liability Limits of the
Contracts will be based upon the final Contract Price of the Contracts as determined at trial. (Id. ¶
6–8).
On June 6, 2008, the parties agreed on the duties that would constitute Voith’s agreed
responsibilities within the Contracts’ “Work” sections, located in Section 1.01.A.60 of the
Contracts’ General Conditions (“GC”). (ECF No. 1 ¶ 19). The Contracts also provide deadlines
(“Milestones”) pursuant to which Voith was obligated to perform. (Id. ¶ 20). If Voith missed the
Milestones, it would be liable to AMP for liquidated damages. (Id.). The Contracts further provide
that Voith warrants that its Work, including the Voith Equipment, will conform to the Contracts
and be free of defects in workmanship and material. (Id. ¶ 24). The Contracts also warrant that all
of Voith’s services included within the Work will be performed in accordance with their
provisions. (Id.).
Excavation and construction on the Cannelton Hydro Project began in 2009; it reached full
commercial operation in June 2016. (Id. ¶ 9). Excavation and construction on the Meldahl Hydro
Project began in August 2011; it reached full commercial operation in April 2016. (Id. ¶ 10).
Excavation and construction on the Willow Island Hydro Project began in September 2010; it
reached full commercial operation in February 2016. (Id. ¶ 11). Excavation and construction on
the Smithland Hydro Project began in December 2009; it reached full commercial operation in
September 2017. (Id. ¶ 12).
3
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 4 of 56 PAGEID #: 63361
According to AMP, Voith’s performance was less than satisfactory in completing the
aforementioned projects. Voith allegedly committed the following errors with respect to its Work
with AMP: (i) “delivering drawings and equipment late and out of sequence”; (ii) “delivering
defective, incomplete and uncoordinated drawings and defective installation instructions”; (iii)
“delivering defectively manufactured guide bearings and discharge rings”; (iv) “defectively
designing and/or manufacturing equipment and equipment components”; (v) “delivering
equipment that was not completely and/or properly manufactured and required significant
additional field work to install”; (vi) “failing to deliver ‘Category C’ parts necessary for Voith
Equipment assembly”; (vii) “failing to timely and completely address installation issues with the
Voith Equipment, including but not limited to, failing to timely and completely address turbine
alignment issues”; (viii) “failing to provide check sheets consistent with the Contracts’
specifications”; (ix) “refusing to promptly and accurately address problems with the Voith
Equipment”; (x) “failing to maintain a consistent executive and project management team and site
representatives who were informed and prepared to address ongoing issues”; and (xi) “causing
substantial delay and damage to the Hydro Projects, all in material breach of the Contracts.” (Id. ¶
28).
AMP withheld “approximately $40 million” in payments due to Voith under the Contract
to offset Voith’s alleged material breaches of the Contracts, which caused damages and delays,
“including, inter alia, millions of dollars in additional costs of installation, construction and
engineering, liquidated damages, lost power production and other costs and damages.” (Id. ¶¶ 46–
47). AMP then filed suit.
4
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 5 of 56 PAGEID #: 63362
B. Procedural Background
AMP filed the present action on August 14, 2017, alleging eight counts—the first four
alleging breaches of contract with respect to each of the four projects at issue and the last four
alleging breach of warranty claims. (ECF No. 1). In turn, Voith filed a counterclaim with its
answer (ECF No. 22) alleging that AMP agreed to pay Voith a lump sum for each Hydro Project,
which included the costs of designing, manufacturing, and supplying the equipment and the costs
for startup, testing the equipment, and training AMP personnel. (Id. ¶ 15). The Contracts also
provided allowances for each Project against which Voith could bill for its oversight of the
assembly and installation of the equipment. (Id. ¶ 21). During the projects, the parties entered into
other Memoranda of Understanding (“MOU”) and updated agreements. (Id. ¶ 28). Voith now
alleges that AMP has failed to comply with its contractual obligations such that Voith cannot
realize the bargained-for economies of scale, and that AMP’s conduct deprived Voith of the benefit
of its bargain on the Hydro Projects. (Id. ¶ 30). In its counterclaim, therefore, Voith asserted breach
of contract for the withheld payments and unjust enrichment. (Id. ¶ 75–90).
Following several years of discovery, Voith filed the first of six motions for partial
summary judgment on April 4, 2022. (ECF No. 257). AMP filed its Motion for Partial Summary
Judgment on the same date. (ECF No. 275). The parties argued their summary judgment motions
before the Court on September 19, 2022, (ECF No. 370), and the motions are now ripe for
disposition.
II. STANDARD OF REVIEW
Summary judgment is appropriate “if the movant shows that there is no genuine dispute as
to any material fact and the movant is entitled to judgment as a matter of law.” Fed. R. Civ. P.
5
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 6 of 56 PAGEID #: 63363
56(a); Maben v. Thelen, 887 F.3d 252, 258 (6th Cir. 2018). This Court’s function at the summary
judgment stage is not “to weigh the evidence and determine the truth of the matter but to determine
whether there is a genuine issue for trial.” Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 249
(1986). And “there is no issue for trial unless there is sufficient evidence favoring the nonmoving
party for a jury to return a verdict for that party,” but evidence that is “merely colorable” or “not
significantly probative,” however, is not enough to defeat summary judgment. Id. at 249–50.
The party seeking summary judgment carries the initial burden of presenting this Court
with law and argument in support of its motion as well as identifying the relevant portions of “‘the
pleadings, depositions, answers to interrogatories, and admissions on file, together with the
affidavits, if any,’ which it believes demonstrate the absence of a genuine issue of material fact.”
Celotex Corp. v. Catrett, 477 U.S. 317, 323 (1986) (quoting Fed. R. Civ. P. 56). If this initial
burden is satisfied, the burden then shifts to the nonmoving party to set forth specific facts showing
that there is a genuine issue for trial. See Fed. R. Civ. P. 56(e); see Anderson, 477 U.S. at 250.
In considering the factual allegations and evidence presented in a motion for summary
judgment, this Court “views factual evidence in the light most favorable to the non-moving party
and draws all reasonable inferences in that party’s favor.” Barrett v. Whirlpool Corp., 556 F.3d
502, 511 (6th Cir. 2009). “The mere existence of a scintilla of evidence to support [the non-moving
party’s] position will be insufficient; there must be evidence on which the jury could reasonably
find for the [non-moving party].” Copeland v. Machulis, 57 F.3d 476, 479 (6th Cir. 1995).
III.
LAW & ANALYSIS
The district court should not award summary judgment when there exists a “genuine issue
of material fact regarding ambiguous terms in the contract.” Royal Ins. Co. of Am. v. Orient
Overseas Container Line Ltd., 525 F.3d 409, 422 (6th Cir. 2008). In those instances, “a jury and
6
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 7 of 56 PAGEID #: 63364
not a judge must consider extrinsic evidence when the contract’s language does not make clear the
intent of the parties.” Id. Both parties contend that the clear and unambiguous meanings of the
disputed contractual terms support their readings. As the Sixth Circuit has held, “[c]ontract
language is ambiguous if it is subject to two reasonable interpretations.” Schachner v. Blue Cross
& Blue Shield of Ohio, 77 F.3d 889, 893 (6th Cir. 1996). The Court must first determine that a
contract provision is ambiguous before “it may use traditional methods of contract interpretation
to resolve the ambiguity, including drawing inferences and presumptions and introducing extrinsic
evidence.” Id. This Court “may not, however, use extrinsic evidence to create an ambiguity,” id.;
instead, “the ambiguity must be patent; that is, apparent on the face of the contract.” Id.
In Voith’s six motions for partial summary judgment, it groups AMP’s eight claims into
six “categories”:
Future costs in the amount of $53,000,000 to design, manufacture and install new discharge
rings in AMP’s plant machinery to replace the 11 allegedly defective discharge rings that
are currently in use at each of the projects (“Discharge Ring Claims”);
Liquidated damages in the amount of $11,664,026 for Voith’s allegedly late equipment
deliveries on the Cannelton project (“Late Equipment Claims”);
Payments that AMP made to its installation contractors due to delays on the projects
allegedly caused by Voith and for which it seeks reimbursement in the amount of
$8,517,962 (“Delay Damages Claims”);
109 individual “additional work” claims in the total amount of $4,226,475, which AMP
contends it paid to its installation contractors pursuant to Potential Change Order claims
(“PCOs”) due to defects in Voith’s Work (“Additional Work Claims”);
7
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 8 of 56 PAGEID #: 63365
281 individual “defective work” claims in the total amount of $14,611,632, which AMP
contends it paid to its installation contractors pursuant to PCO claims (“Defective Work
Claims”). This category includes a subset of 69 PCO claims totaling $10,026,011 that AMP
alleges are related to alignment issues (“Alignment and Tolerance Claims”);
Liquidated damages in the amount of $21,863,076 for Voith’s allegedly late submittals of
various drawings, instructions, and related information enabling AMP to install and use
Voith’s supplied equipment (“Late Submittals Claim”).
(ECF No. 257 at 1–2).
In turn, AMP affirmatively argues that it is entitled to summary judgment in its favor on
all of the claims that Voith disputes in its six motions for partial summary judgment. AMP’s
motion further seeks summary judgment with respect to the following of Voith’s counterclaims:
$5,590,870 for the difference between Voith’s purported costs of providing field service
work on the Projects and the current Field Service Allowance as allegedly approved by the
parties through purported Change Orders (“FSA Claim”).
$4,478,175 in additional compensation for purported “extra work” performed under Work
Change Directives issued by AMP (“Work Change Directive Claim”).
$19,462,886 for various other Change Requests Voith submitted during the course of the
Projects (“Change Request Claim”).
(ECF No. 275 at 11–12). Voith asserts for most of its claims that the relevant Contract
provisions are unambiguous; thus, there is no genuine dispute of material fact concerning whether
Voith is liable for AMP’s asserted claims. In the alternative, Voith asserts that AMP has not put
forth evidence to rebut Voith’s evidence demonstrating that it is not liable for AMP’s claims.
8
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 9 of 56 PAGEID #: 63366
AMP’s assertions in its Motion for Partial Summary Judgment follow the same general structure.
This Court first addresses each of Voith’s Motions for Partial Summary Judgment in turn, then
discusses AMP’s Motion for Summary Judgment.
A. Voith’s Motions for Partial Summary Judgment
1. The Discharge Ring Claims
In Voith’s first Motion for Partial Summary Judgment, Voith seeks summary judgment in
its favor concerning AMP’s claim for future costs incurred from Voith’s alleged act of providing
AMP with defective discharge rings (“the Discharge Ring Claims”). AMP’s allegations in its
Complaint (ECF No. 1) can be summarized as follows. AMP asserts its claims under both a breach
of contract theory and a breach of warranty theory. Under the Contracts, Voith was required to
design, manufacture, and deliver a total of 11 turbine and generator units to the four plants and to
provide oversight and technical advice to installation contractors that AMP hired directly to
construct the power plants and to install the Voith equipment in those power plants. AMP’s claims
are based in part on the contention that the discharge rings within the turbine and generator units
were defectively designed and/or manufactured. Therefore, AMP’s claimed damages of
approximately $53,000,000 are based on the amount that it contends it would cost to design,
manufacture, and install the new replacement rings. The parties agree that the discharge rings fall
under the warranty process in Section 5.09 of the General Conditions, but dispute the meaning and
application of that section, in particular subsections G-L.
a. Voith’s Argument
Voith argues the following. First, AMP cannot sustain its breach of contract claim because
Section 5.09 limits its remedies to the contents therein—and AMP did not fulfill the necessary
9
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 10 of 56 PAGEID #: 63367
conditions of providing Voith the opportunity to resolve the issue as required before fixing it
themselves. Section 5.09.F unambiguously bars AMP’s desired relief given that the remedies
contained therein are “expressly in lieu of all other warranties, express or implied.” Section 5.09.F
provides the following:
THE WARRANTIES UNDER PARAGRAPHS 5.09.A, 5.09.B, 5.09.C, AND
5.09D ARE EXPRESSLY IN LIEU OF ALL OTHER WARRANTIES, EXPRESS
OR IMPLIED. All other warranties, including but not limited to any implied
warranties of merchantability and fitness of use, and warranties arising from course
of dealing and usage of trade ARE HEREBY EXCLUDED AND DISCLAIMED.
THE WARRANTIES UNDER PARAGRAPHS 5.09.A, 5.09.B, 5.09.C, AND
5.09.D CONSTITUTE THE ONLY WARRANTIES OF THE CONTRACTOR
WITH RESPECT TO THE WORK.
(Id.). If Voith breaches either of those warranties, AMP is required to provide written notice of the
breach under Section 5.09.G,1 and Voith is then required by Section 5.09.H2 to remedy such
nonconforming Work by adjustment, repair, or replacement of the item at its own cost. Under
Section 5.09.I,3 AMP can correct the defective work itself only if Voith fails to correct it; in that
case Section 5.09.K4 allows AMP to recover the “reasonable” costs to repair or replace defective
1
Section 5.09.G provides:
The Owner shall within a reasonable time notify Contractor in writing of a breach of the
Contractor’s warranties, and the Contract shall, at its sole cost, promptly (a) investigate the nonconforming Work and (b) provide to the Engineer a schedule for the correction of it.
(Id. at 26).
2
Section 5.09.H provides:
In the case of a breach of the warranty described under Paragraph 5.09.C or 5.09.D, the Contractor shall:
1. At its sole cost, remedy such non-conforming Work by, at the mutual agreement between
Owner and Contractor, adjustment or repair or replacement of the item, and any other affected
part of the Work, or by re-performance of the service, or in the case of Work covered by the
performance guarantees described under Agreement Sections 4.3 and 4.4 by payment of the
associated liquidated damages or the parties may agree that the Owner will accept the nonconforming Work under the conditions of paragraph 8.03(D).
(Id.).
3
Section 5.09.I provides:
At all appropriate times throughout the performance of the Work, the Contract must contact, meet,
consult, and otherwise coordinate with the Owner, the Engineer, and others for the purpose of
facilitating the Project’s design and execution of the Work.
(Id).
4
Section 5.09.K provides:
If the Owner corrects non-conforming Work as described under Paragraph 5.09.I or 5.09.J, the
Owner may deduct from the Contract Price all of the reasonable costs described under Paragraph
10
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 11 of 56 PAGEID #: 63368
work itself, but only if AMP takes steps to repair or replace the work and actually “incurs” costs
in doing so. Finally, Section 5.09.L5 clearly and unambiguously states that the remedies specified
in Section 5.09.H are AMP’s “sole and exclusive remedy” for breach of the relevant warranties.
When AMP gave Voith notice of a crack in the discharge rings, Voith pursued correction
of that work at its own cost. Voith argues that AMP was required to incur costs in connection with
replacing the discharge rings as a condition precedent to reimbursement from Voith. See Ramsey
v. Penn Mut. Life Ins. Co., 787 F.3d 813, 822 (6th Cir. 2015) (“Ohio law defines a condition
precedent as ‘one that is to be performed before the agreement becomes effective. It calls for the
happening of some event, or the performance of some act, . . . before the contract shall be binding
on the parties.’”). Second, AMP’s breach of warranty claims also fail because it has presented no
evidence that it has suffered any damages from the allegedly defective rings—AMP never
corrected any of the allegedly defective rings nor incurred costs from doing so.
Beyond this, Voith suggests that AMP cannot prove that the exclusive warranty remedy
failed of its essential purpose because a remedy can only fail of its essential purpose if the buyer
did not fully avail itself of the remedy. See Siriano v. Goodman Mfg. Co., L.P., No. 2:14-cv-1131,
2015 U.S. Dist. LEXIS 191458, at *28 (S.D. Ohio Aug. 18, 2015). AMP did not do so here because
it did not correct the Work and then seek reimbursement.
5.09.H that the Owner incurs to correct the defective Work. If those costs exceed the unpaid
balance of the Contract Price, the Contractor must immediately pay the difference to the Owner.
(Id.).
Section 5.09.L provides:
Paragraphs 5.09.G, 5.09.H, 5.09.I, 5.09.J, [and] 5.09.K…
2. Describe the Owner’s sole and exclusive remedy for a breach of the warranties described
under Paragraph 5.09.C and 5.09.D whether in contract or in tort or under any other legal
theory, and whether arising out of warranties, representations, instructions, installations or
defects from any cause…
(Id. at 26–27).
5
11
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 12 of 56 PAGEID #: 63369
b. AMP’s Response
AMP pursues two independent causes of action to recover the full cost of replacement for
the defective rings: (1) it is entitled, under the warranty provision of the Contracts to recover the
full cost of replacement of the rings which cannot be repaired to meet contractual requirements;
and (2) AMP is entitled to compensatory damages in an amount equal to the full cost of replacing
the defective discharge rings given that Voith materially breached the Contracts by providing the
defective rings. Voith materially breached both its contractual obligation to deliver the specified
discharge rings and its warranty under the Contracts that its Work would not be defective.
AMP argues that Mead Corp. v. ABB Power Generation, Inc., 319 F.3d 790 (6th Cir. 2003),
stands for the proposition that, “breach of contract should be generally available to plaintiffs as an
alternative theory of recovery [to breach of warranty].” Id. at 793. Thus, AMP argues, the existence
of the warranty as an additional remedy available to AMP would only preclude AMP’s breach of
contract claim for Voith’s failure to repair the discharge rings to meet contractual requirements or
to otherwise reimburse AMP if the warranty “state[d] an exclusive remedy” or “limit[ed] the
plaintiff from claiming damages as the result of faulty work or materials.” Id. at 796. According
to AMP, the warranty at issue here does neither. In the alternative, AMP argues that it is entitled
to recover money damages under a “repair or replace warranty” theory, See Ohio Rev. Code §§
1302.88–1302.89, 1302.93, because Voith has not and cannot repair the rings.
With respect to the first cause of action, AMP argues that its warranty claim is not subject
to dismissal because Voith materially breached its obligation under Section 5.09.H.1. by failing to
repair properly the defective discharge rings, an independent breach of contract in itself. Voith has
acknowledged that the rings have repeatedly cracked; thus, whether Voith has repaired the rings
or if it can do so at all is an issue precluding summary judgment. But AMP is entitled to recover
12
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 13 of 56 PAGEID #: 63370
from Voith the full cost of replacing the discharge rings if AMP proves Voith did not or could not
repair them. Voith argues by expert testimony that it has made the repairs and has produced proof
in the record showing the repeated repairs.
Concerning the second cause of action, AMP argues that the Contracts do not make AMP’s
actual completion of the repairs a condition precedent to Voith’s obligation to pay to replace them
under the warranty. The warranty provides instead that, when Voith fails to repair, AMP “may
correct the non-conforming Work without giving further notice to the Contractor,” (ECF No. 1-1
at 26), and AMP may deduct from the Contract Price all reasonable costs incurred to correct the
defective Work. (ECF No. 1-1 at 26). But the provision of GC 5.09.K, which states that “[i]f the
Owner corrects non-conforming Work . . . the Owner may deduct from the Contract Price all of
the reasonable costs described under GC 5.09.H that the Owner incurs to correct the defective
Work,” does not require AMP to incur costs to fix the issue when Voith fails to repair or replace.
Further, AMP argues that it can show that it suffered damages from Voith’s defective rings
cracking thirty-four times to date. AMP will also produce at trial evidence of the estimated costs
to replace the discharge rings.
c. This Court’s Findings
The Court GRANTS summary judgment to Voith on the Defective Rings Claims. Under
Ohio law, the Court must first determine the existence of the actual fact of damage before assessing
the amount of damage. City of Gahanna v. Eastgate Properties, Inc., 36 Ohio St. 3d 65, 68, 521
N.E.2d 814, 818 (1988) (holding that, “in order for a plaintiff to recover [damages] in a breach of
contract action that amount . . . as well as their existence, must be demonstrated with reasonable
certainty.”). Section 5.09.F unambiguously provides that the warranties as provided under Sections
5.09A, 5.09B, 5.09C, and 5.09D are the exclusive and sole warranties concerning these claims. To
13
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 14 of 56 PAGEID #: 63371
be clear, AMP’s breach of contract and breach of warranty claims do not rest on Sections 5.09A,
B, C, or D.
Section 5.09.K states that “[i]f the Owner corrects non-conforming Work as described
under Paragraph 5.09.I or 5.09.J, the Owner may deduct from the Contract Price all of the
reasonable costs described under Paragraph 5.09.H that the Owner incurs to correct the defective
Work.” The effect of the term “if” is to “impose[] a condition on” the following terms. See Dodd
v. United States, 545 U.S. 353, 358 (2005) (finding that “the definition of ‘if’ is ‘in the event that’
or ‘on condition that.’”). The word “if” thus carries the same function as other words that Ohio
courts have found indicative of conditional language such as “condition,” “conditional,”
“contingent,” “subject to,” and “unless.” See Grigoryan v. MaxOut Sports, L.L.C., 2017-Ohio6982, 94 N.E.3d 1214, 1221, ¶ 26 (8th Dist.); accord Campbell v. George J. Igel & Co., 2013Ohio-3584, 3 N.E.3d 219, 225, ¶ 19 (4th Dist.). And “[a] condition precedent is a condition that
must be performed before obligations in a contract become effective.” Transtar Elec., Inc. v.
A.E.M. Elec. Servs. Corp., 140 Ohio St. 3d 193, 198, 2014-Ohio-3095, 16 N.E.3d 645, 650, ¶ 18.
The Court thus finds that Section 5.09.K is unambiguous that the Owner must actually
“correct[] [the] non-conforming Work” before it may deduct “all of the reasonable costs . . . Owner
incurs to correct the defective Work.” To this point, the record does not show that AMP
demonstrated that it incurred costs to correct the defective Work. Having failed to demonstrate
that it fulfilled the condition precedent of incurring costs to correct the Work, AMP cannot
demonstrate that Voith had any obligations at all to reimburse. As such, summary judgment in
Voith’s favor is warranted as to AMP’s claim for $53,000,000 in alleged replacement costs.
14
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 15 of 56 PAGEID #: 63372
2. The Equipment LD Claim
a. Voith’s Argument
In Voith’s second Motion for Partial Summary Judgment (ECF No. 258), Voith seeks
summary judgment in its favor concerning AMP’s claim for liquidated damages due to Voith’s
late delivery of equipment (“Equipment LD Claim”). Voith argues that damages in breach of
contract actions require that there be actual harm and it is uncontested that Voith’s equipment
deliveries did not delay the Project and did not cause any actual harm. Voith contends that the
relevant delivery obligations and dates were established by Cannelton Contract Section 3.2 (ECF
No. 1-1 at 4), as modified by the parties’ May 2012 Memorandum of Understanding (“MOU”)
(Butler Decl., Ex. 33).
AMP entered into separate contracts for the supply of the turbine and generator equipment
to be installed at each of AMP’s four power plants. Voith’s Work included shipping and delivering
the equipment components to the Cannelton site, as provided in Section 1.01.A.60. The Cannelton
Contract provided for liquidated damages if Voith missed an Equipment Delivery Milestone date.
Voith does not dispute that it delivered at least some of the components late. The Milestones were
modified on several occasions via Change Orders. As relevant here, the parties executed Change
Order 20 with an MOU attached in May 2012. (ECF No. 258-8). Attached to the MOU was the
“TKB Structure Table,” which broke down the Equipment Delivery Milestone table into individual
components. The MOU included a section entitled “Settlement Terms,” in which “[b]oth [p]arties
agree to work together and finalize the TKB Structure Tables which will form the basis for the
amended schedule in the Change Orders[.]” The MOU also contained language concerning
liquidated damages for equipment deliveries. Voith argues that Change Order 20 settled all claims
over previous late deliveries and required the parties to work together to agree on new delivery
15
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 16 of 56 PAGEID #: 63373
dates for the remaining components. The parties never executed a subsequent change order with
finalized dates. Voith attributes this to the Installation Contractor being behind schedule and
subsequently repeatedly changing the schedule for the work, impacting its need for various
equipment.
Voith argues that the liquidated damages provision as established by Section 3.2 of the
Cannelton Contract is an unenforceable penalty because it does not represent actual damages. First,
Voith argues, the only reasonable interpretation of the contract as modified by the MOU is that
liquidated damages are assessed only if the equipment delivery delays the critical path of the
project. On Voith’s read, Section E of the MOU uses clear language—the TKB Structure Tables
were to be finalized in the future to form the basis for change orders for all four projects, including
Cannelton. Reading the “Equipment Delivery Liquidated Damages” section of Change Order 20
(ECF No. 258-8) confirms, according to Voith, that liquidated damages for equipment deliveries
on all projects were only triggered if there was a critical path delay and no concurrent delay by the
installation contractor.
Voith asserts that AMP never disputed that there was no critical path delay from the late
deliveries, nor that Voith was coordinating deliveries to meet the contractor’s schedule with the
knowledge and approval of AMP and its representative, MWH. Further, AMP has not adduced
any evidence demonstrating that the equipment deliveries delayed the critical path of the project,
so there is no basis on which to conclude that a critical path delay occurred that would warrant
imposing liquidated damages. Voith cites as evidence deposition testimony from a contractor that
he informed AMP repeatedly between 2012 and 2017 that “[l]iquidated damages for late deliveries
are $21,000 for each day after the Contract Delivery Date provided the delay is impacting a critical
path activity on the Project construction schedule.” (ECF No. 212-6 at 134:6–136:25).
16
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 17 of 56 PAGEID #: 63374
Second, Voith suggests that AMP adduced no evidence that there was not a concurrent
delay by the installation contractor. And the second sentence of the relevant MOU provision states
that “[n]o LDs will be due from Voith in the event there is a concurrent delay by the GC and Voith
at the time of delivery by Voith.” (ECF No. 258-8). Third, the equipment delivery liquidated
damages provision of the Cannelton Contract is an unenforceable penalty because it seeks to
charge Voith $21,000 per day, regardless of whether equipment deliveries delayed final
completion of the project. But, says Voith, it is inappropriate for an owner to assess liquidated
damages when the owner or someone for whom he is responsible is a cause of delay.
Besides, according to Voith, the only evidence that AMP suffered any damage at all is
expert Ken Fisher’s testimony that those damages represent one day of lost ability to generate
power. But since power can only be generated once the plant was complete, the deliveries would
have had to cause a delay to the final completion of the project, which they did not. And there can
be no damages for a breach of contract where there is no demonstrable harm resulting from the
breach. Kline v. Mortg. Elec. Sec. Sys., 154 F. Supp. 3d 567, 604 (S.D. Ohio 2015) (“Under Ohio
law, there can generally be no viable action for breach of a contract where the plaintiff cannot
show that it has suffered damages flowing from the alleged breach.” (citations omitted)). As such,
there is no basis on which to assess liquidated damages.
b. AMP’s Response
AMP responds that Change Order 20 in fact documented the parties’ agreement to replace
the original table with the “TKB Structure Table.” The MOU was not an “agreement to agree” on
Equipment Delivery Milestones—Change Order 20 expressly provided that the TKB Table now
established the new Milestones. Further, the original Milestones were in large part unchanged after
the execution of the MOU. The parties did discuss potential future modifications to the
17
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 18 of 56 PAGEID #: 63375
Milestones—but, as Voith acknowledges, this was never executed. None of the discussions
between parties’ representatives on coordination of deliveries constituted a Modification
cognizable under the Contract. Although AMP never asserted a Late Equipment Claim during the
course of the project, AMP claims that the Contracts do not require it to do so for such a claim to
be valid. Section 3.96 of the Agreement reads in part: “[i]n addition to other rights that the Owner
may have relative to liquidated damages, the Owner may deduct liquidated damages from the
Contract Price as the damages accrue provided notice of Owner’s intent to do so has been given to
the Contractor.” (ECF No. 1-1 at 5–6). Section 14.19 of the Cannelton Contract also includes a
“No Waiver” clause that provides:
The failure of the Owner . . . to insist in any one or more instances upon the strict
performance of any one or more of the provisions of the Contract or to exercise any
rights under the Contract . . . will not be construed as a waiver or relinquishment of
that provision or right or of the right to subsequently demand strict performance or
exercise the right and the rights will continue unchanged and remain in full force
and effect.
(ECF No. 1-1 at 53). AMP did not need to withhold money from Voith during the project for late
equipment deliveries to retain the right to do so.
AMP posits that the only material fact is the terms of the parties’ Contract. First, Section
3.2 of the Cannelton Contract is unambiguous that liquidated damages are assessed for late
equipment deliveries regardless of the impact on the project construction schedule;7 this was not
Section 3.9 provides:
“In addition to other rights that the Owner may have relative to liquidated damages, the Owner
may deduct liquidated damages from the Contract Price as the damages accrue provided notice of
Owner’s intent to do so has been given to the Contractor. If payment then or thereafter due the
Contractor are not sufficient to cover such amounts, the Contractor must immediately pay the
difference to the Owner.”
(ECF No. 1-1 at 5).
7
Section 3.2 provides:
If the Contractor fails to achieve one or more of the Equipment Delivery Milestones (adjusted as
provided in the Contract), the Owner and Contractor acknowledge that it would be difficult, if not
impossible, to determine the actual damages to the Owner. Consequently, the Owner and the
Contractor agree that as liquidated damages and the Owner’s sole and exclusive remedy, but not as
6
18
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 19 of 56 PAGEID #: 63376
changed by the MOU because that only tied late equipment liquidated damages to a critical path
delay for the other three projects. Second, according to AMP, the liquidated damages provision in
this Contract are enforceable under the test provided in Samson Sales, Inc. v. Honeywell, Inc.
because (1) the damages are “uncertain as to amount and difficult of proof”; (2) “the contract as a
whole is not so manifestly unconscionable, unreasonable, and disproportionate in amount as to
justify the conclusion that it does not express the true intention of the parties”; and (3) “the contract
is consistent with the conclusion that it was the intention of the parties that damages in the amount
stated should follow the breach thereof.” 12 Ohio St. 3d 27, 28, 465 N.E.2d 392, 394 (1984).
Further, argues AMP, the parties here are equally sophisticated and the evidence shows that AMP
considered multiple types of probable damages that would result from late equipment deliveries
when establishing the liquidated damages rate. Third, AMP contends that this Court must disregard
Voith’s extrinsic evidence because the contracts are unambiguous. Lastly, AMP argues that it was
not required to rule out concurrent delays because Section 3.2 of the Cannelton Contract renders
Voith liable for liquidated damages when it “fails to achieve one or more of the Equipment
Delivery Milestones” regardless of concurrent delays to the Project schedule. (ECF No. 1-1 at 4).
c. This Court’s Findings
The Court DENIES Voith’s Second Motion for Partial Summary Judgment. The
“Equipment Delivery Liquidated Damages” section of the MOU is unambiguous. Although it is
true that the MOU provides that “[n]o LDs will be due from Voith in the event there is a concurrent
delay by the GC [General Contractor] and Voith at the time of delivery by Voith,” Voith has the
a penalty, the Contractor must, at the Owner’s option, pay to or credit the Owner $21,000 per day
for each day after the expiration [of] the associated Contract Time that the Contractor fails [to]
achieve an Equipment Delivery Milestone.
(ECF No. 1-1 at 4).
19
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 20 of 56 PAGEID #: 63377
responsibility of affirmatively proving that there was a concurrent delay to avoid liability—as
opposed to AMP having the burden to prove that there was not. But the Court finds that there is a
genuine dispute of material fact concerning whether there was indeed a concurrent delay within
the meaning of the Contracts. Voith alleges that it had to coordinate deliveries with AMP to meet
the installation contractor’s changing schedule, causing some of the delays. AMP disputes that this
was a contributor to the delay. As such, whether there existed a “concurrent delay” such that Voith
escapes liability is a triable issue of fact.
This Court also finds that the Contract unambiguously provides that the critical path
analysis requirement specifically applies to the change orders for the other three projects—not for
the Cannelton Project. As such, AMP need not demonstrate that there was a critical path delay to
receive its liquidated damages for these claims coming under the Cannelton Contract.
Finally, this Court finds that the liquidated damages clause is enforceable. Applying the
factors articulated in Samson Sales, 465 N.E.2d at 394, the record supports a finding that liquidated
damages is proper: this contract was carefully negotiated and entered into by sophisticated parties,
providing a mechanism for awarding damages that the record supports are otherwise uncertain and
difficult to prove. Further, this Court does not view this Contract as unconscionable such that it
does not express the parties’ intent, and the contract is consistent with the parties’ clearly expressed
intent that damages in that monetary amount should follow the breach. Id. After all, as the Ohio
Supreme Court has noted, “findings of unconscionability” are rare in a commercial context.
Chemtrol Adhesives, Inc. v. Am. Mfrs. Mut. Ins. Co., 42 Ohio St. 3d 40, 55, 537 N.E.2d 624, 639
(1989). This is especially true in cases like this “where there is no great disparity of bargaining
power between the parties.” Id. The Court notes that the project at issue is a large-scale one, and
20
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 21 of 56 PAGEID #: 63378
it does not appear unreasonable within the context of the large financial sums at stake that
liquidated damages for a day’s delay be set at $21,000.
3. Delay Damages Claims
a. Voith’s Argument
In Voith’s third motion, Voith seeks summary judgment on the $8,517,962 to which AMP
claims entitlement under Section 3.5 of the Contracts. AMP seeks reimbursement for the additional
monies it paid to installation contractors due to delays caused by alleged deficiencies in Voith’s
work across the four projects. Voith refers to these as the “Delay Damages Claims.” Voith argues
that the entirety of AMP’s Delay Damages Claims set forth in its Exhibit 2 can be resolved
completely in Voith’s favor by application of the unambiguous provisions of the parties’ Contracts
to the undisputed facts. (ECF No. 259-2). AMP did not present Voith with these Delay Damages
Claims during the Projects which, if provided, should include support of contemporaneous daily
project cost records as required by the Contracts. So, Voith argues that it is entitled to summary
judgment because: (1) one of the conditions precedent to Voith’s reimbursement obligation has
not been satisfied because AMP did not provide daily time sheets for all related costs; and (2) the
contracts unambiguously limit Voith’s reimbursement obligation to the actual direct costs incurred
by the installation contract due to delay caused by defects in Voith’s work, and AMP’s delay
damage calculation is not based on this. Voith is only responsible for costs incurred by installation
contractors associated with defects in Voith’s Work as set forth in Section 3.5 of the Agreements
to the Contracts. (ECF No. 1 at 24–25). Section 5.2.1 reaffirms the limitations on recoverable
damages.8
8
Section 5.2.1, entitled “Waiver of Consequential Damages,” provides:
21
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 22 of 56 PAGEID #: 63379
On the first point, Voith argues, AMP did not provide daily time sheets reflecting
contractors’ costs, but the Contracts unambiguously provides that this is a condition precedent to
receiving reimbursement. AMP does not even argue that it did so. AMP admitted, through the
deposition of both its expert, William Schwartzkopf (ECF No. 259-5 at 8), and its corporate
representative, Mr. Crusse (ECF No. 259-6 at 3–4, 6), that AMP did not use daily time sheets to
calculate the reimbursement amounts it seeks to recover. Second, although Section 3.5.2 states that
Voith’s reimbursement obligation is limited to the “actual direct costs” incurred by the installation
contractors caused by the delay, AMP admits that the Delay Damages Claims are not calculated
using “actual direct costs.” And under Section 5.2.1, indirect costs are clearly and expressly
excluded. Without daily time sheets, there is no evidence of the actual direct costs incurred by the
installation contractors due to delays caused by alleged defects in Voith’s work. Lacking evidence
of actual direct costs, AMP and its experts resorted to the calculation of a daily rate based on
general conditions costs, which are indirect costs. The result is a Delay Damages Claims
calculation based on estimated indirect costs as opposed to actual direct costs, which is contrary
to the clear requirements of Section 3.5.
b. AMP’s Response
AMP responds that the time-related costs for which AMP seeks reimbursement are not the
type recorded on daily time sheets; therefore, AMP has fully satisfied all the requirements of
Section 3.5 of the Contracts. In any event, AMP’s Delay Damages Claims are based on the actual
costs incurred by the contractors directly attributable to Voith-caused delays. Section 3.5 sets out
In no event will the Contractor’s liability to the Owner under any legal theory whatsoever include
liability for consequential, incidental or indirect damages of any kind or for loss of use or loss of
income or loss of profit or loss of revenue or loss of financing or cost of capital or loss of business
and/or reputation, or for loss of management or employee productivity.
(ECF No. 1-1 at 7).
22
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 23 of 56 PAGEID #: 63380
the relevant reimbursement provisions. AMP engaged in a multi-step analysis to establish its Delay
Damages claims: first, it provided a critical path analysis9 of each of the Project schedules prepared
by AMP’s expert, Schwartzkopf; second, Schwartzkopf used Project records, interviews with
personnel, and opinions of other experts to determine which of the issues causing the delays were
due to defects in Voith’s Work; third, Schwartzkopf identified the Voith-caused critical path delays
for which the Installation Contractors were compensated and the amount that AMP paid to them
for those delays; fourth, AMP’s expert William Kime, using the Project’s actual cost records and
interviews with representatives of the Contractors, calculated the costs actually incurred by the
Contractors due to the critical path delays; and last, Schwartzkopf calculated the Delay Damages
Claims by comparing the amount AMP paid to the Contractors on account of delays caused by
defects in Voith’s Work to the amount of costs actually incurred by the Contractors on account of
the delays caused by defects in Voith’s Work and to the contractual cap provided in Section 3.5.2.
AMP further argues that Section 3.5 of the Contracts provides that Voith must reimburse
AMP if AMP incurs costs to compensate third parties for costs incurred by the third parties because
of delays to the Project completion caused by defects in Voith’s Work. (ECF No. 1-1 at 4–5). AMP
contends that Section 3.5 places no limitation on the types of reimbursable costs that may be
included in the third-party claims submitted to AMP, other than to limit Voith’s liability to “actual
direct” costs of the Installation Contractors. The claims for which AMP seeks reimbursement are
actual direct time-related costs incurred due to delays caused by Voith’s defective Work, none of
which includes costs that can be recorded in daily increments. Instead, the costs for which AMP
is seeking reimbursement in its Delay Damages Claims are extended time-related “general
9
This critical path analysis was conducted to establish the issues that caused critical path delays to the Project
schedules.
23
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 24 of 56 PAGEID #: 63381
conditions costs,” i.e., direct costs incurred because of the passage of time, not in specifically
identifiable daily increments. Further, AMP expert William Kime stated in his expert reports and
at deposition that the costs were not estimates but were actually incurred and paid by the
Installation Contractors. (ECF No. 324-9 ¶ 5). According to AMP, the relevant inquiry is whether
the costs included in AMP’s Delay Damages Claims are “actual direct costs of the Installation
Contractor caused by the delay” as the phrase is used in Section 3.5 of the Contracts.
c. This Court’s Findings
The Court DENIES Voith’s third Motion for Partial Summary Judgment. As previously
stated, “[c]ontract language is ambiguous if it is subject to two reasonable interpretations.”
Schachner, 77 F.3d at 893. Voith cannot simply ask the Court to assume that AMP’s costs cannot
be “actual direct costs” because they are categorized as “general conditions costs.” Both parties
have a reasonable read of the daily time sheet requirement under Section 3.5 of the General
Conditions. The “subject to the limitations and conditions” language used in Section 3.5 makes it
such that providing the “daily time sheets for all related costs on a daily basis” under Section
3.5.510 is a condition precedent to reimbursement. But, on AMP’s read, the word “related” means
that only costs that can be appropriately categorized in a time sheet need be submitted to invoke
Voith’s reimbursement obligation. Conversely, Voith reads “related” seemingly to mean that all
costs that have any relation to the delay claims must be categorized in a time sheet. AMP produces
no evidence that it provided time sheets on these claims; therefore, if Voith’s reading is found to
reflect the intent of the parties, AMP loses on these claims. The Contract is ambiguous, however,
on this point, and the parties submitted competing evidence relating to the parties’ intent in
10
Section 3.5.5 provides that “[t]he Owner will provide daily time sheets for all related costs on a daily basis.” (ECF
No. 1-1 at 5).
24
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 25 of 56 PAGEID #: 63382
agreeing to the provision. Further, whether AMP’s Delay Damages Claims otherwise constitute
“actual direct costs of the Installation Contractor caused by the delay,” which Section 3.5.2. of the
Contracts indicates are the only costs reimbursable under Section 3.5 is also a genuine issue of
material fact upon which parties submit competing evidence. As such, summary judgment is
improper.
4. Additional Work Claims
a. Voith’s Arguments
In Voith’s fourth motion, Voith seeks summary judgment on the $4,226,475 in damages
that AMP seeks for “additional work required as a result of Voith’s acts, errors and omissions, in
the amount paid to the Installation Contractors for the performance of that work.” (ECF No. 260
at 5). The damages reflect the amounts AMP allegedly paid to Installation Contractors pursuant to
109 individual Potential Change Order (“PCO”) claims for those costs. Voith terms these the
“Additional Work Claims.” Voith argues that it is entitled to summary judgment because: (1) the
Contracts unambiguously preclude the recovery of damages for the Additional Work Claims; and
(2) AMP does not produce adequate expert testimony to establish proximate causation between
the 109 individual Additional Work Claims and any fault of Voith.
First, Voith suggests that no contractual provision allows AMP to pursue claims for
payments made to other contractors to pursue additional work that did not constitute repair or
replacement for Voith’s defective Work. In his report, for each of the four projects, Schwartzkopf
identified four categories of damages to which he claims AMP is entitled: Defective Work,
Additional Work, Critical Path Delays, and Equipment Delivery Delays. His report categorizes
costs “to repair, modify, and correct defective work” in the Defective Work category. Additional
Work is described as costs “to perform additional work that was not originally contemplated for
25
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 26 of 56 PAGEID #: 63383
the Cannelton Project.” According to Voith, there is no contractual provision, however, requiring
Voith to reimburse AMP for work not originally in the scope of work of AMP’s Installation
Contractors. It cannot be true that the Additional Work Claims consist of defective work damages,
as AMP asserts. The largest Additional Work Claim at Cannelton relates to the need to add climate
control to the storage of stators and rotors (PCO 256 for $63,487)—this is work the Installation
Contractors would have had to perform anyway. Instead, Voith alleges that AMP’s Additional
Work Claims constitute consequential damages precluded by the Waiver of Consequential
Damages provision, located at Section 5.2.1, which provides: “[i]n no event will the Contractor’s
liability to the Owner under any legal theory whatsoever include liability for consequential,
incidental or indirect damages of any kind.” Further, Voith argues that the warranty provisions of
Section 5.09 of the Contracts limit AMP to the costs to repair or replace defective Voith work.
Section 5.09.H.4 of the Contract provides that Voith is not responsible for “costs incurred or losses
suffered by others associated with warranty Work except as stated in Agreement Section 3.5 and
General Conditions Paragraph 5.09.H.2.” (ECF No. 1-1 at 26). AMP is already seeking damages
elsewhere under Section 3.5 and has asserted no claims for costs under 5.09.H.2.
Second, Voith argues that, even if AMP could pursue these claims, it cannot establish
proximate causation between each of the 109 individual Additional Work Claims and any alleged
act, error or omission by Voith. Because the claims involve complicated engineering design,
manufacture and onsite services beyond the understanding of a lay person, proof of proximate
causation requires expert testimony. Not one of AMP’s experts, however, offer any testimony at
all to establish the requisite proximate causation.
26
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 27 of 56 PAGEID #: 63384
b. AMP’s Response
AMP argues that Section 5.09 of the General Conditions of the Contracts provides the basis
for AMP’s Additional Work Claims. AMP disputes the allegation that these claims are not related
to remedying defects in Voith’s Work—in fact, the Installation Contractors were directed, in some
cases by Voith itself, to remedy defects in Voith’s Work. AMP argues that there are genuine
disputes between the parties, not properly resolved on summary judgment, regarding the following
material facts: (i) whether each of the PCOs included in AMP’s Additional Work Claims relates
to a defect or non-conformance in Voith’s Work; and (ii) whether the cost of the work performed
by the Installation Contractors was performed to remedy such a defect or nonconformance, or is
otherwise within the costs for which Voith is responsible under Sections 5.09 and 10.04.C of the
General Conditions of the Contracts.
On the first point, AMP argues that the Contract does provide for damages in this instance.
If Voith provided a defective part, Section 5.09 makes Voith responsible for all costs associated
with remedying that non-conformance. The only way to determine whether any individual claim
included within the “Additional Work Claims” includes costs that are recoverable under Section
5.09 of the General Conditions of the Contracts is to review the evidence relating to that individual
PCO. This is not an exercise that can be disposed of on summary judgment and Voith does not
even attempt to establish that any individual PCO is improperly included within the PCO Claims.
On the second point, the issue of causation is not proper for determination at summary judgment.
AMP claims it will prove at trial that each of the individual POCs was caused by defects in Voith’s
Work. Many of the PCOs do not involve any complex engineering issues and/or are within the
knowledgeability of the fact witnesses that Mr. Schwartzkopf relied on in his expert reports and
deposition.
27
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 28 of 56 PAGEID #: 63385
c. This Court’s Findings
The Court GRANTS Voith’s fourth Motion for Partial Summary Judgment. Section 5.09.K
provides relief for these “Additional Work Claims” to the extent that they comprise costs incurred
by AMP for the purpose of “correct[ing] [the] non-conforming Work.” (ECF No. 1-1 at 26). AMP
contends that its Additional Work Claims proceed on two independent theories: breach of contract
and breach of warranty.
Under Ohio law, a plaintiff must demonstrate the following to establish a claim for breach
of express warranty: “(1) a warranty existed; (2) the product failed to perform as warranted; (3)
plaintiff provided the defendant with reasonable notice of the defect; and (4) plaintiff suffered
injury as a result of the defect.” Caterpillar Fin. Servs. Corp. v. Harold Tatman & Son's Ents.,
Inc., 2015-Ohio-4884, 50 N.E.3d 955, 960, ¶ 9 (4th Dist.). Similarly, to demonstrate breach of
contract under Ohio law, the plaintiff must show: “the existence of a contract, the failure without
legal excuse of the other party to perform when performance is due, and damages or loss resulting
from the breach.” Lucarell v. Nationwide Mut. Ins. Co., 152 Ohio St. 3d 453, 463, 2018-Ohio-15,
97 N.E.3d 458, 469. To establish damages, the plaintiff must show that “the breach of the warranty
was the proximate cause of the loss sustained.” Thompson I.G., LLC v. Edgetech I.G. Inc., 590 F.
App’x 532, 537–38 (6th Cir. 2014). In other words, a plaintiff’s failure to produce proper evidence
of proximate cause warrants summary judgment on a breach of warranty or a breach of contract
claim. Id. at 537.
AMP asserts that its Additional Work Claims comprise its claims for reimbursement of
amounts that AMP paid to Installation Contractors for work they performed to remedy defects in
Voith’s Work. In essence, the Court’s inquiry at summary judgment is whether AMP demonstrates
that Voith’s defective work was the proximate cause of the damages AMP asserts in its Additional
28
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 29 of 56 PAGEID #: 63386
Work Claims. AMP’s Additional Work Claims seek reimbursement for AMP’s own damages from
incurring extra costs to have contractors fix the deficiencies in Voith’s work instead of concerning
“costs incurred or losses suffered by others,” which is covered in Section 5.09.H.4.11 The evidence
adduced by AMP, however, fails to create a triable issue as to causation between the PCOs listed
as Additional Work Claims and Voith’s allegedly defective product. Although AMP offers to
produce the relevant testimony and circumstantial evidence at trial, AMP must offer some
evidence that the “breach . . . was causally related to the injury” to survive summary judgment. Id.
at 538. And here, AMP has not shown how the alleged defects in Voith’s work proximately caused
damages in the form and amount of the payments AMP made to the Installation Contractors for
work performed to ostensibly fix the defects. As such, summary judgment is proper.
5. Alignment and Tolerance Claims
a. Voith’s Argument
In its fifth Motion for Partial Summary Judgment, Voith disputes AMP’s claims of
entitlement to reimbursement for $10,026,011 that it was allegedly forced to pay the Installation
Contractors pursuant to 69 individual Potential Change Order (“PCO”) claims for equipment
alignment necessitated by alleged defects in Voith’s Work. Voith refers to these claims as “the
Alignment and Tolerance Claims.”
Voith argues that: (1) AMP’s Contracts with Voith and its Contracts with the Installation
Contractors unambiguously make the Installation Contractors responsible for aligning Voith’s
equipment—not Voith; and (2) AMP cannot show proximate causation between the 69 individual
11
Section 5.09.H.4 provides that “[i]n the case of a breach of the warranty described under Paragraph 5.09.C or
5.09.D, the Contractor shall not be responsible for costs incurred or losses suffered by others associated with
warranty Work except as stated in Agreement Section 3.5 and General Conditions Paragraph 5.09.H.2.” (ECF No. 11 at 26).
29
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 30 of 56 PAGEID #: 63387
Alignment and Tolerance Claims and any defect of Voith because this requires expert testimony
that AMP does not have. On Voith’s read, Paragraph 5.09.I requires AMP to give notice to Voith
of the nonconforming Work, then to allow Voith to fail to begin correcting it promptly, before
correcting the Work without further notice. But, says Voith, AMP did not do this nor does it argue
that it did. After all, Voith argues, General Conditions Section 5.01.L indicates that Voith has no
responsibility for the outcome of the alignment labor that the Installment Contractors engaged in.
Section 5.01.L provides the following:
The Contractor’s obligations under this Contract do not include the installation of
the Work, and notwithstanding Paragraphs 5.12 through 5.22 of these General
Conditions or any other provision of the Contract, the Contract is not intended to
transfer to the Contract any of the responsibilities of the Installation Contractor.
(ECF No. 1-1 at 24). Voith posits that AMP’s effort to shoulder it with responsibility for the
equipment alignment derives from Specifications Section 14-05.B.112 of the Voith Contracts, but
that section is internally contradictory on the nature of Voith’s responsibility. Instead, Voith argues
that Section 6.3513 made clear that Voith’s instructions were “provided only to give the general
Section 14-05.B of the Cannelton Contract, entitled “Oversight of the Site Work,” provides:
1. The Contractor shall, when directed by the Engineer, furnish one or more competent, full time
supervising erectors and test engineers who shall oversee and advise the Installation
Contractor in matters of methods, procedures, and precautions to be followed. The Contractor
shall be responsible for proper alignments, adjustments, clearances, inspection, field testing of
the equipment, and other matters pertaining to the quality of the installation and/or testing of
the equipment. The Installation Contractor will furnish the necessary skilled and unskilled
labor and facilities required for erection purposes and will be responsible for the progress of
the Work. The supervising erector and the Contractor shall be responsible for the proper
performance of the installation Work unless he notifies the Owner in writing that the Work is
being performed contrary to his instructions, immediately upon such occurrence. The
supervising erector and the Contractor shall be responsible for starting, initial operation,
commissioning and performance testing of the equipment and shall make final adjustments
prior to Commercial Operation.
(ECF No. 262-13 at 5).
13
Section 6.35-1.06 of the Cannelton Contract, entitled “General Requirements,” provides:
A. The descriptions of the major equipment and installation and field testing requirements
contained in this Section and as shown on the Drawings, and on the appended manufacturer's
drawings and instructions (Part 8 Reference Documents of these Specifications) are provided
only to give the general scope of the Work and are not intended to be inclusive of all
equipment items, installation Work, and testing. After procurement of the equipment by the
Owner, the manufacturers' drawings and instructions required for its installation will be
12
30
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 31 of 56 PAGEID #: 63388
scope of the Work” and that the contractors may be required to “supply and install temporary
bracing, supports and other materials as required . . . whether or not this is indicated on the T/G
equipment drawing.” Voith maintains that the contractual exclusion of liability in Section 5.01.L
of its General Conditions was “a bargained for ‘allocation of commercial risk [which] should not
be disturbed.’” Ind. Mich. Power Co. v. Siemens Energy, Inc., Case No. 2:12-cv-861, 2013 U.S.
Dist. LEXIS 121852, at *23–24 (S.D. Ohio Aug. 27, 2013). Lastly, Voith contends that AMP
failed to provide the expert testimony necessary to demonstrate causation between Voith’s action
and each of AMP’s 69 unique Alignment and Tolerance Claims.
b. AMP’s Response
AMP responds that Section 5.09 of the General Conditions of the Contracts provide the
basis for AMP’s PCO Claims (which include the “Alignment and Tolerance Claims”), and that
Parts 5,14 6,15 6A,16 and 1417 of the Contracts expressly obligate Voith to perform the Work that
Voith performed defectively, which caused AMP to incur the costs associated with Alignment and
Tolerance Claims.18 First, Sections 5.09 and 10.04.C19 of the General Conditions (ECF No. 1-1 at
furnished for use by the Contractor. OFE shall be installed and tested in accordance with said
drawings and instructions unless otherwise specifically directed. In the event of discrepancies
between sources of information, the decision of the Engineer shall govern.
(ECF No. 262-9 at 10).
14
ECF No. 257-3.
15
ECF No. 267-1 at 149–79.
16
ECF No. 263-2.
17
ECF No. 262-13.
18
The Court here notes that “Sections” and “Parts” of the Contract refer to different documents and sets of
provisions; they are not interchangeable terms.
19
General Conditions Section 10.04.C provides:
If the Owner is entitled to reimbursement or payment from the Contractor, the Contractor shall
make that payment immediately upon demand by the Owner. Notwithstanding anything contained
in the Contract Documents to the contrary, in addition to the Owner’s other rights under the
Contract Documents, if the Contractor fails to immediately make any payment due to the Owner,
or the Owner incurs any costs and expenses to cover the default of the Contact or to correct
defective Work, the Owner shall have the absolute right to offset such amount against the Contract
Price and may, in the Owner’s sole discretion, elect either to: (a) deduct an amount equal to that
which the Owner is entitled from any payment then or thereafter due the Contractor from the
31
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 32 of 56 PAGEID #: 63389
25–27, 44) of the Contracts require Voith to pay for these claims because the work that was
performed by the Installation Contractors were to (1) “remedy the non-conformance” of Voith’s
Work; (2) was work to remedy “any other affected part of Voith’s Work”; (3) was performed to
“gain[] access to the non-conforming Work of Voith”; and/or (4) was performed to “reinstall
corrected Work” (i.e., to correct a non-conformance in Voith’s Work). Voith’s Work obligations
specifically include: (1) all of the oversight and advice Voith was required to provide pursuant to
Part 14 of the Contract; (2) the bracing design and installation instructions it was required to
provide pursuant to Part 6 of the Contract; (3) the design and manufacture of various pieces of
equipment, including the guide bearings it was required to perform pursuant to Part 5 of the
Contracts; (4) and the drawings and submittals it was required to prepare pursuant to Part 6A of
the Contracts. Where Voith provided defective equipment or services, Voith is responsible for all
costs associated with remedying those defects, including all of the costs included in the “Alignment
and Tolerance Claims.” Part 14 unambiguously states that Voith is “responsible for proper
performance of the installation Work” unless Voith notifies AMP that the Installation Contractors
are failing to perform in accordance with Voith’s instructions.
According to AMP, notwithstanding Voith’s claims that Section 5.01.L shows that the
Contractors were solely responsible for all responsibilities related to the alignment, the Contractors
were obligated to perform work outside of its enumerated responsibilities due to Voith’s defects.
Thus, to the extent that the “Alignment and Tolerance Claims” arise out of defects in Voith’s
performance of those Voith obligations (as opposed to out of Voith’s failure to “achieve proper
alignment”), AMP claims Section 5.01.L has no application and Voith is obligated with the costs
Owner, or (b) issue a written notice to the Contractor reducing the Contract Price by an amount
equal to that which the Owner is entitled.
(ECF No. 1-1 at 44).
32
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 33 of 56 PAGEID #: 63390
associated therewith. AMP argues that Voith’s warranty obligations under Section 5.09 of the
Contracts require Voith to pay for all of the costs associated with remedying its defective Work.
In addition to the warranty provision, argues AMP, Section 10.04.C provides that AMP may offset
the amount against the Contract Price that it incurs to correct Voith’s defective work. AMP
contends that, because all of the PCOs included in the Alignment and Tolerance Claims involve
work that was performed by the Installation Contractors to remedy one or more defects in Voith’s
Work, Voith is responsible for all of the costs associated with those PCOs. AMP lastly argues that
it will prove proximate cause at trial, demonstrating that each of the costs associated with each of
the individual PCOs under this set of claims were incurred to remedy defects in Voith’s Work.
c. This Court’s Findings
The Court DENIES Voith’s fifth Motion for Partial Summary Judgment. Contrary to
Voith’s argument, General Conditions 5.01.L does not impact the outcome of this claim because
it does not concern the question of Voith’s liability for the defective installation. First, the section
within which GC 5.01.L is located discusses only what the direct responsibilities of the Contractor
are (i.e., what work it is responsible for doing). AMP’s claim, however, is that Voith’s failure to
carry out its non-installation responsibilities resulted in additional costs relating to the installation
of the Work because the other Contractors had to perform additional work. Even so, Section 5.01.L
also indicates that the Contract is not intended to transfer to the Contractor any of the
responsibilities of the Installation Contract “notwithstanding Paragraphs 5.12 through 5.22 of these
General Conditions or any other provision of the Contract.” (ECF No. 1-1 at 24) (emphasis added).
Considering this, GC 5.01.L does not bar AMP’s claims seeking reimbursement for fixing Voith’s
defective Work, which caused the Contractor to submit claims for the additional alignment and
tolerance work that resulted. The parties present genuine issues of material fact concerning
33
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 34 of 56 PAGEID #: 63391
whether Voith’s Work fell below the standards required by the Contract and if so, whether AMP’s
“Alignment and Tolerance Claims” were causally related to those defects. Unlike with respect to
the Additional Work Claims, AMP’s evidence—consisting of expert witnesses, contemporaneous
correspondence between the parties, and fact witnesses—creates at least a triable issue on the
question of causation. Voith’s secondary causation argument, that expert testimony is required for
all claims instead of on a case-by-case basis, fails for the same reason that it fails in its fourth
motion. See supra Part III.A.4.
6. Late Submittals Claim
a. Voith’s Argument
In Voith’s sixth Motion for Partial Summary Judgment, Voith disputes AMP’s claim for
$21,863,076 in liquidated damages for Voith’s alleged failure to achieve Submittal Milestones,
which Voith terms the “Late Submittals Claim.” Voith’s scope of work included the submission
of various drawings, illustrations and other materials (defined by the Contracts as “Submittals”)
for contractually-defined portions of Voith’s equipment, to MWH for review and approval. (ECF
No. 263-2). The Submittals provided information for MWH to evaluate whether the design of
individual components of the equipment complied with the Contracts. (ECF No. 263-3). The
Contracts contained Submittal Milestones that set the deadlines by which Voith was to deliver the
Submittals to MWH. Section 3.1.2 of the Agreement specified that Voith was required to deliver
the Submittals as set forth in Part 6A and Appendix 6A-1. Part 6A contained a list of the
Submittals, Appendix 6A-1 of the Contracts specified the deadlines for achieving the Milestones,
and Section 3.3 of the Agreement specified a per diem amount of liquidated damages that Voith
would owe AMP for each day after the Submittal Milestone deadline that Voith failed to achieve.
AMP’s claim amount was calculated by applying the per diem late fee to every individual submittal
34
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 35 of 56 PAGEID #: 63392
delivered late; but Voith argues that the Contract provides that the per diem should be applied such
that damages are only assessed for the entire Submittal Milestone. To provide illustration, under
Voith’s interpretation, if a Submittal Milestone included 20 individual submittals, Voith delivered
all 20 individual submittals 10 days late, and the per diem liquidated damages fine was $100, the
proper liquidated damage calculation would be $100 x 10 days = $1,000. Under AMP’s
interpretation, the per diem applies to every individual submittal delivered late, such that the same
20 individual submittals delivered 10 days late would be calculated as $100 x 10 days x 20
individual submittals = $20,000.
Voith argues that the General Conditions define “Submittals” in a manner indicating that a
Submittal may be comprised of multiple submitted items. Voith claims that its interpretation
reflects the true intent of the parties: Even in defining “Milestone” in General Conditions
Paragraph 1.01.37, the parties agreed that it constituted a “principal event specified in the Contract
Documents relating to an intermediate completion date or time prior to the Contract Times.” (ECF
No. 1-1 at 34). Voith contends that this contemplates that the Milestones are either achieved on a
certain date or not—there are no individualized subdivisions. On May 17, 2012, the parties signed
an MOU to resolve various disputed issues, including one concerning liquidated damages for late
submittals. Voith asserts that the MOU resolved that dispute in two respects: (1) Voith paid AMP
$2 million in satisfaction of all submittal liquidated damages claims AMP had asserted as of the
date of the MOU; and (2) it set new deadlines for all outstanding Submittal Milestones. On Voith’s
read, the Contract Times are expressly described in Article 3.1 to be the dates set forth in Appendix
6A-1 to Part 6A for achievement of Submittal Milestones. (ECF No. 1 at 23).
In addition, Voith argues that the liquidated damages provision set forth in Article 3.3
provide that the liquidated damages are intended to compensate AMP for actual damages it might
35
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 36 of 56 PAGEID #: 63393
incur if Voith “fails to achieve one or more of the Submittal Milestones.” (Id. at 24). Thus, says
Voith, liquidated damages are to be assessed only for the number of days by which a Submittal
Milestone remains incomplete after the due date, regardless of how many individual submittals
were still outstanding on the due date. Voith contends that, to perform their work properly, AMP,
MWH, and the Installation Contractors needed the complete Submittal Milestone, not just isolated
bits and pieces of it. Thus, Voith asserts, the potential actual harm that liquidated damages were
intended to address was the potential for delay to the Project as a result of Voith’s failure to achieve
the complete Submittal Milestone by the due date.
b. AMP’s Response
AMP counters that the unambiguous language of the Contracts provides that liquidated
damages are assessed on a per drawing basis. Section 3.3, which provide the payment schedule for
damages from Voith’s failure to achieve one or more of the Milestones, delineates the fees for
each type of submittal. Section 3.3 provides that Voith agreed to pay liquidated damages if it “fails
to achieve a Submittal Milestone for any other Submittals”, i.e., on a submittal-by-submittal basis,
not “for a Submittal Milestone” as Voith now argues. (ECF No. 1-1 at 24). AMP alleges that
Voith’s suggestion is absurd that AMP would have intended a contractual provision that did not
distinguish between whether one or 100 drawings are late; there is certainly a difference to AMP
between waiting for 100 late drawings and instead waiting for one late drawing while working
from the other 99. The MOU and the Contracts are clear that Voith is liable to AMP for liquidated
damages on each drawing that is submitted late. AMP contends that the Court must disregard
Voith’s extrinsic evidence because the Contracts are unambiguous. But even if the Contracts were
found to be ambiguous, Voith’s evidence would still be insufficient to establish that the parties
intended that liquidated damages be assessed on a per-Submittal Milestone basis.
36
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 37 of 56 PAGEID #: 63394
c. This Court’s Findings
This Court DENIES Voith’s sixth Motion for Partial Summary Judgment. The Contract is
unclear on whether liquidated damages should be assessed on an individual deliverable or a
collective basis. The parties debate the import of the language of Section 3.3 itself, the structure
of the Submittal Milestones in Appendix 6A-1, and the language of Part 6A of the Contracts. Both
parties’ reading of the language is reasonable, supporting the Court’s finding that the Contract is
ambiguous on this issue. Schachner, 77 F.3d at 893. The parties dispute the sufficiency of one
another’s proffered evidence offered to prove their reading or to disprove the other. Further, the
adoption of one party’s reading over that of another—creating liability for either the individual
submissions or collective ones—impacts the fact of liability with respect to several of the claims.
So, while it is true that “summary judgment may be appropriate even if ambiguity lurks as long as
the extrinsic evidence presented to the court supports only one of the conflicting interpretations,”
the Sixth Circuit has also held, “[o]n the other hand, if the extrinsic evidence relevant to the
interpretation of an ambiguous contractual provision is contested or contradictory, summary
judgment will often be inappropriate.” GenCorp, Inc. v. Am. Int’l Underwriters, 178 F.3d 804, 818
(6th Cir. 1999). As such, this motion is denied.
B. AMP’s Motion for Partial Summary Judgment
1. AMP’s Late Delivery of Drawings Claims
a. AMP’s Argument
AMP first argues that its claims for liquidated damages (“LDs”) with respect to Voith’s
late delivery of drawings are ripe for summary judgment. Voith moved for summary judgment on
this issue in its fifth and sixth Motions for Partial Summary Judgment. AMP’s claim concerns
three groupings of late equipment LDs: (1) LDs for the late Submittals that were outstanding before
37
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 38 of 56 PAGEID #: 63395
the parties signed their MOU providing, inter alia, that “Voith will pay a $2M LD for late
submittals to be allocated evenly across all four projects, which will not be assessed until the end
of each Project,” (ECF No. 258-8 at 8); (2) LDs for late Submittals that occurred post-MOU but
which Voith acknowledged were properly assessed; and (3) LDs for late Submittals that occurred
post-MOU but the assessment of which Voith disputes.
AMP argues that the Cannelton Contract, GC 6.02 (ECF No. 1-1 at 32), required Voith to
deliver equipment in accordance with established Equipment Delivery Milestones, set forth in a
table at Section 3.1 of the Cannelton Agreement. (ECF No. 1-1 at 4). AMP contends that the
liability was set at $21,000 per day for each day that Voith was late, as set forth in Section 3.2 of
the Cannelton Contract. (ECF No. 1-1 at 4). The parties later changed the dates via the MOU
incorporated into the Contract by Change Order 20 (ECF No. 258-8), which replaced the table in
Section 3.1 with the TKB Structure Table. (Butler Decl. ¶ 4, Ex. 33). The only material facts
relating to this claim are: (i) the applicable Equipment Delivery Milestones (established by the
plain language of the Change Orders); (ii) the dates that Voith delivered equipment (shown in
Appendix B of this motion); and (iii) the rate of LDs to which AMP is entitled (the plain language
of the Cannelton Contract). The Contract can be interpreted as a matter of law. Two LD provisions
are at issue—Agreement Section 3.3 concerning the late drawings claim and Section 3.2 of the
Cannelton Contract concerning the late equipment. The provisions each unambiguously provide a
basis for AMP’s LD claims.
Concerning the first group of LD claims for $2 million in LDs ($500,000 for each of the
four Projects), AMP argues that the May 17, 2012 MOU expressly provides that Voith would pay
the claim amount in full to satisfy the late Submittals submitted before the MOU. (ECF No. 2588 at 8). Because there are no issues of fact with respect to the first set of claims, AMP contends,
38
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 39 of 56 PAGEID #: 63396
summary judgment is warranted. Concerning the second group of LD claims, AMP suggests that
it is entitled to summary judgment on those post-MOU drawings because Voith’s expert
acknowledged in his expert report that the corresponding damages were properly assessed. (ECF
No. 272-7). Both the second and third group of LD claims are due summary judgment given that
the Milestones were never modified, and that record indicates that Voith submitted the drawings
at dates later than the Milestones provided. Voith argues that the Equipment Delivery Milestones
were amended after the MOU, but this was wrong—the later Change Orders did not impact these
milestones and the communications that Voith alleges changed the arrangements were not
modifications following the agreed-upon process. Modifications to the Contract may only be made
through signed writings; Voith has presented no evidence that the parties had any agreement, oral
or otherwise, to waive the provision of the Contracts that required a signed writing to modify the
Contracts.
b. Voith’s Response
Voith responds that, as an initial matter, much of AMP’s evidence is inadmissible because
Tabs A through D to AMP’s Appendix A (ECF No. 261-1) are not project records, and they lack
supporting testimony by a witness with knowledge. On the first set of LD claims, AMP’s failure
to pay outstanding invoices for Voith’s Work constitute material breaches of the Contracts which
excuse Voith’s performance to pay the $2,000,000 claim for the pre-MOU Submittal LDs. Besides,
Voith argues that, under Paragraph 14.24.A.1 of the General Conditions, it can offset whatever
amounts it may owe AMP under the Contracts against the damages AMP owes Voith for breaching
the Contracts. With respect to the second set of claims, which AMP claimed Voith admitted were
valid, Voith counters that its expert never agreed that AMP is entitled to be paid the supposedly
agreed-upon amounts; he only acknowledged that AMP properly calculated those amounts
39
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 40 of 56 PAGEID #: 63397
assuming liability was proven by AMP. Concerning the third set (the LDs for late Submittals that
occurred post-MOU but the proper assessment of which is in dispute), Voith argues that AMP is
not entitled to summary judgment for the drawings submitted after the new Submittal Milestones
established by the May 17, 2012, MOU because Voith disputes that Submittal LDs should be
assessed based on each and every individual Submittal that is late; instead, Voith suggests the LDs
should be assessed only for each day that an entire Submittal Milestone remained incomplete after
the due date. At any rate, Voith contends, the LDs here constitute an unenforceable penalty.
c.
This Court’s Findings
The Court GRANTS summary judgment as to the first portion of AMP’s claim relating to
whether the MOU required Voith to pay $2 million in LDs for the late Submittals outstanding
before May 17, 2012. The MOU, incorporated into the Contract, unambiguously states that “Voith
will pay a $2M LD for late submittals to be allocated evenly across all four projects, which will
not be assessed until the end of each Project.” (ECF No. 258-8 at 8). Voith does not dispute AMP’s
reading of the MOU nor raise a genuine issue of material fact concerning this claim.
However, the Court DENIES summary judgment with respect to the second and third
group of claims. As AMP argues, the material facts bearing on these claims are: (i) the applicable
Equipment Delivery Milestones (as established by the plain language of the Change Orders); (ii)
the dates that Voith delivered equipment; and (iii) the rate of LDs to which AMP is entitled
(provided for in the plain language of the Cannelton Contract). Voith does not dispute the accuracy
of the recorded dates on which it delivered the equipment. Additionally, the plain language of the
MOU indicates that it did not change the rate of LDs to which AMP is entitled. The Court finds,
however, that the inquiry of what constituted the operative Equipment Delivery Milestones is a
40
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 41 of 56 PAGEID #: 63398
genuine issue of material fact given that Voith presents evidence that could indicate that the parties
engaged in a course of conduct effectively modifying the Milestones.
This Court observes that “Ohio appellate courts have generally held that an oral waiver of
a ‘non-oral modification’ clause is legally permissible when certain circumstances exist.” Special
Learning, Inc. v. Step by Step Acad., Inc., No. 2:14-CV-126, 2015 WL 10990267, at *6 (S.D. Ohio
Sept. 17, 2015). These “certain circumstances” are present when a party engages in “waiver by
estoppel,” which occurs “when the acts and conduct of a party are inconsistent with an intent to
claim a right and have been such as to mislead the other party to his prejudice and thereby estop
the party having the right from insisting upon it.” Id. Evidence of course of conduct can be
considered “notwithstanding a ‘written changes only’ contractual provision, because the series of
acts in question are evaluated only as evidence regarding a continuity of the purpose captured by
the original contractual terms at the time of formation.” Lincoln Elec. Co. v. St. Paul Fire & Marine
Ins., 210 F.3d 672, 687 (6th Cir. 2000). The question of whether a no-oral-modification clause is
waived by Ohio courts as a question for the trier of fact. Special Learning, Inc., 2015 WL
10990267, at *7.
General Conditions Section 1.01A.38 defines “Modification” as used in the Contract as:
“[a] Written Amendment or addendum to the Contract that is signed by both parties, Change Order,
a Work Change Directive, or a Field Order.” (ECF No. 1-1 at 15). Neither this definition of
“Modification” nor any other provision of the Contract expressly provides that a “Written
Amendment or addendum to the Contract” is the only way to modify the parties’ agreement. In
other words, the clause does not prohibit the parties from modifying the Contract utilizing other
methods. Voith has adduced evidence of conversations between the parties’ representatives which
a jury could find constituted modifications: an example being a November 5, 2013 internal AMP
41
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 42 of 56 PAGEID #: 63399
email acknowledging that AMP had not agreed to Voith’s request to disregard non-field related
documents in assessing Voith’s late submittal LDs, but stating nonetheless that “it is how we have
been calculating LDs to date.” (ECF No. 313-20). Even if the fact-finder determined that this
activity did not constitute a modification within the meaning of the Contract, a jury could find that
the parties’ communications constituted a course of conduct indicative of waiver of the Contract’s
“written changes only” provision. The jury’s conclusion on whether the parties modified the
Contract will be determinative of which deliveries Voith indeed made late and for which it is liable.
Finally, the parties’ dispute, discussed in the “Late Submittals Claim” section, supra Part III.A.6,
regarding whether the LDs are to be assessed for each individual “Submittal” is another question
central to establishing the existence and extent of Voith’s liability; this, too, is a genuine issue of
material fact.
2. AMP’s Defective Discharge Ring Claims
AMP next argues that its claims for breach of contract and breach of warranty arising out
of Voith’s allegedly defective discharge rings are not ripe for summary judgment. Parties’
arguments here were essentially repeated in Voith’s first Motion for Partial Summary Judgment.
The Court granted Voith’s summary judgment motion on those claims, see supra Part III.A.1, and
thus does not readdress the same claims in AMP’s own motion. Therefore, this Court DENIES
AMP’s Motion for Partial Summary Judgment on these claims.
3. AMP’s Late Equipment Delivery Claims
AMP also argues for summary judgment on its claims arising from Voith’s allegedly late
deliveries of equipment. The parties’ arguments are identical to those presented in Voith’s second
Motion for Partial Summary Judgment. See supra Part III.A.2. The Court DENIES summary
42
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 43 of 56 PAGEID #: 63400
judgment on AMP’s Motion for Partial Summary Judgment as relates to this claim for the reasons
articulated in that section.
4. AMP’s Delayed and Defective Work Claims
AMP argues that summary judgment on AMP’s Delay and Defective Work Claims is
improper because there are genuine disputes of material fact relating to, inter alia, whether Voith’s
Work was defective and what resulting damages were caused by those defects.20 AMP then argues,
however, that “the Court can significantly narrow the issues to be tried by interpreting the
Contracts on summary judgment.” (ECF No. 275 at 30). AMP thus argues that, “in order to narrow
the issues to be tried,” this Court should issue summary judgment on the issue of Voith’s liability
for breach of the following obligations: “(i) provide an adequate BTH bracing system; (ii) provide
adequate installation instructions; (iii) properly oversee and advise the Installation Contractors as
to the installation of the BTH and alignment of the BTH components; and (iv) be responsible for
the proper installation and alignment upon completion of the work.” (Id. at 31).
This portion of AMP’s Motion for Partial Summary concerns the following: (1) AMP’s
claim for $8,517,962 for reimbursement of delay damages paid to Installation Contractors for
delays caused by defects in Voith’s Work, pursuant to Agreement Section 3.5 (characterized by
Voith as AMP’s “Delay Claim”); and (2) AMP’s claim for $18,848,423 for reimbursement of
amounts paid to Installation Contractors for Work performed to repair or replace defects in Voith’s
Work for breach of Voith’s obligations under GC 5.09 (characterized by Voith as AMP’s
“Defective Work Claim”).
20
The arguments between the parties on this issue were captured in the briefing on Voith’s third and fifth Motions
for Partial Summary Judgment.
43
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 44 of 56 PAGEID #: 63401
In essence, AMP argues that its Installation Contractors were required to engage in
additional work (AMP’s “Additional Work Claims”) due to Voith’s unsatisfactory Work.
According to AMP, however, Voith disavows liability even if AMP proves that defects in Voith’s
Work caused the alignment difficulties on the reasoning that the Installation Contractors are solely
responsible for installation and alignment. But AMP argues that if GC 5.01.L indeed relieves Voith
of its obligation to oversee the equipment installation work, GC 5.01.L would directly conflict
with Part 14, which details Voith’s obligations in overseeing the installation work.
Voith responds that Paragraph 5.01.L of Voith’s Contracts make clear that, regardless of
whatever agreement AMP later reached with its installation contractors, no provision in Voith’s
Contracts with AMP—including the provisions on which AMP relies in support of its motion—
would make Voith responsible for the work necessary to achieve proper alignment of the
equipment.
This Court DENIES summary judgment on this claim for the reasons stated in the sections
of this Order relating to Voith’s Third and Fifth Motions for Partial Summary Judgment, see supra
pp. 24–25, 33.
5. Voith’s Change Request Claim
a. AMP’s Argument
AMP next argues that it is entitled to summary judgment on several issues concerning
Voith’s counterclaims of $23,941,061 in additional compensation for purported “extra work”
performed under Work Change Directives issued by AMP (“Work Change Directive Claim”) and
for various other Change Requests Voith submitted during the course of the Projects (“Change
Request Claim”). Voith’s claims arise from its issuance of various Change Requests seeking
44
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 45 of 56 PAGEID #: 63402
increases in the Contract Price under each Contract for Work performed on the Projects, including
for Work arising from the various delays on the Projects.
Specifically, AMP seeks summary judgment in its favor with respect to three subsections
of Voith’s claim: (1) the $18,696,097 portion of Voith’s Change Request Claim (ECF No. 275 at
101), on the basis that Voith failed timely to initiate or substantiate Change Requests as required
under the Contracts; (2) the $22,211,784 portion of Voith’s Change Request Claim based on delayrelated Change Requests (Id. at 141), on the basis that Voith failed to provide the necessary delay
or time-impact analysis with those Change Requests and failed to provide any credible evidence
showing that Voith was not responsible for those delays; and (3) the $22,211,784 portion of
Voith’s Change Request Claim based on delay-related Change Requests (Id. at 150–151) on the
basis that Voith failed to prove its actual costs.
AMP makes several arguments concerning this group of claims. First, Voith waived several
of its Change Request claims because it failed to comply with GC 7.06.A of the Contracts. (ECF
No. 1-1 at 35). Here, GC 7.06.A required Voith to initiate its Change Requests within 20 days of
when it knew or should have known of the triggering event giving rise to each Change Request,
or forever waive its right to seek any compensation related to the subject of the Change Request.
Voith was required by GC 7.06.A to meet both the time and content requirements to assert
properly—and avoid waiving—its Change Requests. Table 1 shows that Voith’s Change Requests
were untimely; they were also incomplete because they failed to provide AMP with the “minimum
information” necessary to initiate Voith’s Change Requests under GC 7.06.B or to substantiate its
Change Requests under GC 7.07.B.6. (Id. at 36–37). And Voith never argued that it complied with
GC 7.06 and GC 7.11’s initiation and substantiation requirements. These failures constituted “an
irrevocable waiver” of Voith’s right to any compensation related to the Change Request. Voith’s
45
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 46 of 56 PAGEID #: 63403
argument that AMP waived the requirements by allowing Voith not to follow the process with
respect to several unrelated Change Requests is unavailing: AMP’s mere knowledge of changed
conditions, simple acquiescence to a different course of performance, equivocal conduct, or
conduct of doubtful import are not enough to show waiver. See Vill. of Carthage v. Diekmeier, 79
Ohio St. 323, 342, 87 N.E. 178, 184 (1909). That Voith and AMP included an unequivocal “No
Waiver” provision in GC 14.19.A further supports this view. (ECF No. 1-1 at 53). Whether AMP
followed other provisions of the Contracts in connection with Change Requests not at issue in
AMP’s Motion has no connection to whether AMP intentionally waived GC Article 7’s initiation
and substantiation requirements as to the specific Change Requests at issue.
Second, many of the Change Requests seek increases in the Contract Price due to Project
delays. For Voith to recover on these delay-related claims, GC 7.06 and 7.11 of the Contracts
require Voith first to establish the cause of the delays. (Id. at 35, 37–38). GC 7.11 applies to all
requests by Voith to increase the Contract Price due to delays of Voith’s Work and provides that
any such increase “[is] the sole and exclusive remed[y] for [Voith] and all Subcontractors for all
delays and delay related impacts, inefficiencies, and damages of any kind.” The record shows that,
despite repeated demands, Voith never provided any delay analysis to establish the cause of the
claimed delays—either during the course of the Projects or through affirmative expert testimony
in this litigation—and therefore Voith is unable to prove the cause of the delays for which it seeks
an increase in the Contract Price. Reading GC 7.11.B, GC 7.07.B.4 and GC 7.06.A together, Voith
was required to establish the cause of the delays underlying its delay-related Change Requests to
comply both with the contractual substantiation requirements and to establish its entitlement to
any additional delay-related compensation.
46
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 47 of 56 PAGEID #: 63404
Third, GC 7.11D limits Voith’s Contract Price increases for delay related Change Requests
to “the additional costs [Voith] actually, reasonably, and necessarily incur[red] as a result of a
delay.” But the delay-related damages Voith seeks are not based on actual costs. Fourth, Voith has
priced its Change Request Claim using a “modified” pricing formula that was never properly
entered into effect as a modification consistent with the contract modification requirements of the
Contracts. Instead, the original Change Request pricing formula found in GC 7.09 of the Contracts
remained in place after May 2013.
b. Voith’s Response
Voith argues that AMP is not entitled to summary judgment on the $18,696,097 portion
because AMP has failed strictly to comply with the Change Request provisions of the Contracts
with respect to many of the claims that it is asserting in this lawsuit. The process for handling
change requests are set out in Sections 1.01.9 (defining Change Requests), 7.06(B) and 7.07(A).
But AMP issued Change Orders that Voith then returned unsigned in accordance with an agreedupon procedure for some of the very claims that AMP now claims Voith waived for not strictly
complying with the Change Request requirements of the Contracts. (See, e.g., ECF No. 315-27).
Under the Contract, the Change Request obligations are mutual. But Voith argues that AMP
nonetheless did not first initiate Change Requests for most of its claims, including its $53 million
discharge ring claim, its $11,664,026 claim for equipment delivery liquidated damages, and its
$8,517,962 claim for damages allegedly paid to installation contractors for delays. Even further,
Voith is owed payment on several of the Change Requests that AMP disputes. Voith asserts a
second unjust enrichment claim for the same costs on the basis that AMP’s refusal to pay despite
Voith properly following the Change Request process constitutes a breach of its implied obligation
47
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 48 of 56 PAGEID #: 63405
of good faith and fair dealing, in addition to illegal conversion. This claim, Voith contends, should
survive the Court’s adjudication because AMP did not file summary judgment on that basis.
Voith next argues that AMP is not entitled to summary judgment on the $22,211,784
portion of Voith’s change request claim (Table 2 of AMP’s motion). First, through the execution
of the MOU Change Orders on May 17, 2012, AMP already agreed to compensate Voith for
several of the claims listed in Table 2 that AMP now claims were waived. The MOU stated that
“AMP agrees to pay for justified field/commissioning labor escalation cost.” (Butler Decl. ¶ 4, Ex.
33 at 7). Accordingly, there is no merit to AMP’s assertion that Voith waived its right to be paid
for field labor escalation and commissioning labor escalation (the first two claims in AMP’s Table
2). Second, Section 7.07.D is the only provision in the Change Request substantiation provisions
of the Contract that requires a critical path schedule analysis, and it does not apply to any of Voith’s
time related claims, even if AMP had not waived these Change Request substantiation provisions.
There was no “Contract Time” defined for Voith’s field and commissioning services, and none of
Voith’s claims listed in Table 2 of AMP’s Motion is a claim in which Voith is seeking an increase
in Voith’s Contract Time. Third, Voith argues, abundant evidence supports a finding that its claims
arises out of the Installation Contractors’ delays in completing their work on these Projects. Section
7.11 only applies to requests for an extension of Voith’s “Contract Times” and any resulting
increase in the “Contract Price” arising out of such an extension—not to all manners of Work
delay. Even still, Section 7.11 does not detail the requirements for initiating a Change Request
(contained in Section 7.06) or substantiating a Change Request (contained in Section 7.07), and
the Contracts provide for an “irrevocable waiver” only for “failure to initiate or substantiate a
Change Request”.
48
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 49 of 56 PAGEID #: 63406
Voith next argues that AMP is not entitled to summary judgment on the claims listed in
Table 3 of AMP’s motion because Voith is not required to prove its actual costs as a condition
precedent to reimbursement. First, Voith’s change requests are not subject to Section 7.11; even if
they were, Voith’s change requests are based upon the actual costs that Voith has incurred, which
the evidence shows. Voith tracked the specific hours of the specific employees whose work was
subject to a change request, then provided to AMP the actual rate, per hour, of each individual
employee working on a specific change request. Lastly, Voith is also entitled to the 33% markup
for the change requests. Section 7.11 does not state that recovery is limited to “direct” costs, or
that overhead costs are excluded. Instead, Section 7.11.D, states “[a]ny increase of the Contract
Price under this Section 7.11 is subject to other provisions of the Contract . . . .” (ECF No. 1-1 at
38). The “other provisions of the Contract” include Section 7.09, which entitles Voith to a markup
for the increase in the contract price. (Id. at 37).
c. This Court’s Findings
The Court GRANTS summary judgment to AMP concerning the claims in Table 1;
however, it DENIES AMP’s Motion for Partial Summary Judgment as to the claims in Tables 2
and 3. Evidence of the parties’ course of dealing may be considered only once the Contract is
determined to be ambiguous. See Potti v. Duramed Pharms., Inc., 938 F.2d 641, 647 (6th Cir.
1991) (holding that, under Ohio law, if a contract is ambiguous its interpretation becomes a
question of fact about the parties’ intent). But the Court finds that Section 7.06 is unambiguous
with respect to the Table 1 claims—it provides that the Change Requests must be initiated within
20 days of the relevant determination and that it must contain certain enumerated information.
And, as provided by 7.06.A, failure to initiate and substantiate properly the requests “will
constitute an irrevocable waiver of the Change Request.” Waiver by estoppel “‘exists when the
49
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 50 of 56 PAGEID #: 63407
acts and conduct of a party are inconsistent with an intent to claim a right, and have been such as
to mislead the other party to his prejudice and thereby estop the party having the right from
insisting upon it.’” Hirschvogel Inc. v. Allison Transmission, Inc., No. 2:17-CV-458, 2019 WL
2075934, at *8 (S.D. Ohio May 10, 2019). Here, Voith has not demonstrated that AMP caused it
prejudice as a result of failing consistently to follow the formal process for some of the Change
Requests, nor that AMP’s conduct rises to the level that it is inconsistent with its asserted claims.
Voith does not provide any evidence creating a genuine issue of material fact as to the claims in
Table 1; it instead argues that waiver by estoppel applies by virtue of AMP’s failure itself to
consistently follow the debated provisions of the Contract.
Regarding the claims in Table 2, however, the substantiation provisions under Section
7.07.D unambiguously apply exclusively to Change Requests for an increase of the Contract
Times. And Section 7.11 limits Voith’s requests to increase the Contract Price due to delays of
Voith’s Work such that Voith was limited to damages resulting from AMP’s fault. Voith, however,
raises a genuine issue of material fact concerning whether the Table 2 claims are based on AMP’s
delay. This precludes summary judgment.
This Court finds that the Table 3 claims constitute delay-related claims under Section 7.11;
and Section 7.11.D limits the increases to the additional costs that “the Contractor actually,
reasonably, and necessarily incurs as a result of a delay.” (ECF No. 1-1 at 38). Because Voith
raises a genuine issue of material fact concerning whether it incurred actual costs, however,
summary judgment is improper.
Finally, Voith raises a genuine issue of material fact concerning whether the May 2013
Pricing Formula was adopted consistent with the Contract’s process for making “Modifications.”
Voith and AMP conducted an executive meeting on May 7, 2013, to discuss Voith’s suggestions
50
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 51 of 56 PAGEID #: 63408
to adjust the pricing formula established in Section 7.09. (ECF No. 275 at 161–162). At this
meeting, Voith suggested the formula that the parties refer to as The May 2013 Pricing Formula.
(Id. at 162). The parties, however, disagree on the outcome of that meeting. AMP’s argument that
The May 2013 Pricing Formula could not have been adopted because Contract did not allow for
oral modifications is beside the point; under Ohio law, even express contractual “no-oralmodification” provisions may be waived “when the acts and conduct of a party are inconsistent
with an intent to claim a right and have been such as to mislead the other party to his prejudice and
thereby estop the party having the right from insisting upon it.” See Special Learning, Inc., 2015
WL 10990267, at *6. The parties adduce conflicting evidence on this point: most notably, while
AMP cites minutes from the May 7, 2013 meeting indicating that the status of the pricing formula
was still open afterwards (ECF No. 275 at 162), Voith cites to the same meeting minutes, as well
as contemporaneous notes and subsequent Change Orders indicating that the pricing formula may
have been adopted at the May 7, 2013 meeting (ECF No. 275 at 199–202). Further, the outcome
of this determination impacts whether the May 2013 Pricing Formula indeed applies to these
claims. As such, summary judgment is improper on both the Table 2 and Table 3 claims.
6. Voith’s Claims Concerning its Field Service Allowance (FSA)
a. AMP’s Argument
AMP last argues that Voith’s Field Service Allowance (“FSA”) claim is ripe for summary
judgment. As characterized by AMP, there are two parts of Voith’s claim: (1) a claim for nearly
$4.5 million in unpaid invoices related to field services billed under approved (but unexecuted)
Change Orders; and (2) a claim for over $5.5 million for the difference between its purported final
costs of providing field service Work on the Projects and the current FSA purportedly approved
by both parties through the unexecuted Change Orders.
51
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 52 of 56 PAGEID #: 63409
AMP argues that GC Article 7 required Voith to submit FSA claims that followed the
Change Request process in order to be entitled to receipt—Voith never did this, so it is barred from
recovery. Under Article 7, Voith was required properly to initiate, substantiate, and otherwise
demonstrate its entitlement to an increase of the Contract Price on account of that change in its
scope of Work. Section 7.01.E is clear that “[t]his Article 7 governs the time and compensation
components of all Change Orders, whether additive or deductive; the Contractor’s entitlement to
additional time, compensation, or damages through the Change Request, Claims, and dispute
resolution processes . . . .” (ECF No. 1-1 at 33). And Voith never disputed that it failed to submit
any delay analysis to support Voith’s field service Change Request claims. Voith does not assert
that it provided such analysis to support its claim.
Further, Section 7.06 and 7.11 required Voith to establish the cause of the delays for which
it seeks an increase in the Contract Price before recovering on its FSA Claim—it has not. AMP
argues that, because the FSA Claim is a delay-related claim, Section 7.11.D also unambiguously
limits Voith’s recovery to “the additional costs [Voith] actually, reasonably, and necessarily
incur[red] as a result of a delay.” (ECF No. 1-1 at 38). And the record is clear that the delay-related
damages Voith seeks here are not based on Voith’s actual costs. Contrary to the terms of the
Contracts, Voith supports many of its claims using internal cost estimates and averages without
demonstrating with supporting documentation that these estimates and averages truly represent its
actual costs. Voith also improperly applied Section 7.09’s overhead and profit markup to some of
its delay-related claims, without demonstrating that it actually incurred this amount in overhead
costs or that the overhead costs it seeks are specifically connected to the Projects’ delays at issue.
Most of Voith’s claims seek payment based on The May 2013 Pricing Formula. But the
Contract was never amended to incorporate that formula. Nor did AMP ever agree to apply The
52
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 53 of 56 PAGEID #: 63410
May 2013 Pricing Formula in all instances. Instead, AMP merely agreed to consider alternative
pricing models on a Change-Order-by-Change-Order basis to move the Projects forward. In fact,
the parties continued to dispute the applicable pricing formula after the May 7, 2013, meeting,
until Voith attempted to achieve its desired modification through the proper course on October 3,
2014, by “propos[ing] that AMP issue a Change Order amending [Section] 7.09 . . . to reflect the
May 7, 2013 agreement between the parties.” (ECF No. 277-1 at 34–35). Importantly, however,
AMP rejected this proposal on October 27, 2014. (ECF No. 271-1 at 191–92). Instead, AMP
reiterated its position from the beginning: while AMP “may accept alternative pricing for
subcontractor mark-up,” it was not required to do so and such determinations would be made “on
a case-by-case basis.” (Id. at 192 (emphasis in original).) Further, AMP also made clear that
“[u]nless AMP agrees in writing through the associated [Work Change Directives], Voith will be
expected to comply with the Contract’s change pricing requirements.” (Id.) After all, the Contracts
otherwise do not permit oral modifications. The parties agreed in Section 7.01C that, except in
emergencies, Voith’s “failure to secure a Modification before proceeding with any change in the
Work will constitute an irrevocable waiver of any right that [Voith] may have to any adjustment
of the Contract Price or Contract Times or both on account of the associated change in the Work.”
(ECF No. 1-1 at 32–33). So, the Court should require Voith to comply with the contractual pricing
formula set forth in Section 7.09. Per Section 7.09.A, AMP argues, adjustments to the Contract
Price due to changes in the Work are limited to “the costs associated with the changed Work,” plus
a 33% markup for overhead and profit.
b. Voith’s Response
Voith argues that it need not prove the cause of the Project delays; further, its FSA Claim
recovery is not limited to recovery of its “actual costs”. Section 10.08 provides:
53
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 54 of 56 PAGEID #: 63411
If the final cost of the Contractor’s services during construction is more than or less
than the identified allowance amount (all of which shall be based upon the unit
prices described in the Agreement), the parties shall adjust the Contract Price by
Change Order. The amount of the Change Order shall reflect the difference between
final cost and the allowance amount.
(ECF No. 1-1 at 45). By the language of the Contract, there is nothing that Voith was required to
provide to substantiate its FSA claim other than identify the number of days (i.e., “units”) that it
provided field services. Voith contends that the Contract provides that “the process for reconciling
the [field services] allowance is described at Part 4, General Conditions, Paragraph 10.08.” (ECF
No. 1-1 at 3). And Paragraph 10.08 of the General Conditions dictates that if the cost of Voith’s
field services exceeds the allowance, AMP was obligated to issue a Change Order adjusting the
Contract Price.
Lastly, Voith argues that the May 2013 Pricing Formula modified and superseded the
original formula provided for under Section 7.09. The meeting minutes from a May 7, 2013,
executive meeting shows that the parties agreed to use the Pricing Formula in calculating markup
for changes to Voith’s work “moving forward,” and the parties’ subsequent pattern of conduct
reflects that. (ECF No. 271-1 at 187–188). The parties repeatedly executed Change Orders across
all the Projects that were based upon the revised pricing method agreed upon at the May 7, 2013,
meeting. (See, e.g., ECF No. 317-19). Although Section 1.01.A.38 only lists four ways to modify
the Contract, nothing states that these are the only methods to do so. Even if they did, “[a]n oral
modification of a written contract can be enforceable notwithstanding a provision in the contract
requiring modifications to be in writing where, as alleged here, the parties have engaged in a course
of conduct in conformance with the oral modification and where the party seeking to enforce the
oral modification would suffer injury if the modification were deemed invalid.” Exact Software N.
54
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 55 of 56 PAGEID #: 63412
Am., Inc., Inc. v. Infocon Sys., 2004 U.S. Dist. LEXIS 7580, at *15 (N.D. Ohio Apr. 16, 2004)
(citing Lincoln Elec. Co., 210 F.3d at 687).
c. This Court’s Findings
The Court GRANTS AMP’s summary judgment motion with respect to Voith’s FSA
Claims. Cannelton Agreement Section 2.221 sets out that Voith has an allotted FSA budget,
specifying that the process for reconciling the allowance is in Section 10.08. (ECF 1-1 No. at 4).
That provision indicates that where the final cost of the Contractor’s services goes beyond the
allowance, the parties shall adjust the Contract Price by Change Order. Voith’s FSA claim
coverage, however, is based on costs it incurred for alleged AMP-caused delays. As such, the FSA
claims are subject to the initiation and substantiation requirements of Section 7.11. (Id. at 37–38).
Section 7.06.A sets forth Voith’s obligations to initiate and substantiate properly a Change
Request, failing the execution of which Voith makes “an irrevocable waiver of the Change Request
and any associated Claim which the Contractor could otherwise assert under the Contract.” (Id. at
35). Section 7.07.C requires that Voith initiate each relevant Change Request within 20 days after
Voith “became aware of or should have become aware of the occurrence of the event giving rise
to the Change Request.” (Id. at 35–36). Voith fails to demonstrate that it complied with these
requirements or that these requirements were otherwise waived or supplanted by other provisions.
As such, summary judgment is proper.
21
Section 2.2 provides:
If the Contractor fails to achieve one of more of the Equipment Delivery Milestones (adjusted as
provided in the Contract), the Owner and Contractor acknowledge that it would be difficult, if not
impossible, to determine the actual damages to the Owner. Consequently, the Owner and the
Contractor agree that as liquidated damages and the Owner’s sole and exclusive remedy, but not as
a penalty, the Contractor must, at the Owner’s option, pay to or credit the Owner $21,000 per day
for each day after the expiration the associated Contract Time that the Contractor fails [sic]
achieve an Equipment Delivery Milestone.
(ECF No. 1-1 at 4).
55
Case: 2:17-cv-00708-ALM-EPD Doc #: 420 Filed: 10/19/22 Page: 56 of 56 PAGEID #: 63413
IV.
CONCLUSION
Given the foregoing analysis, Voith’s First and Fourth Motions for Partial Summary
Judgment (ECF Nos. 257, 260) is GRANTED, while Voith’s Second, Third, Fifth, and Sixth
Motions for Partial Summary Judgment (ECF Nos. 258, 259, 262, and 263) are DENIED. AMP’s
Motion for Summary Judgment (ECF No. 275) is GRANTED in part and DENIED in part.
IT IS SO ORDERED.
ALGENON L. MARBLEY
CHIEF UNITED STATES DISTRICT JUDGE
DATED: October 19, 2022
56
Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.
Why Is My Information Online?