American Waste Management and Recycling, LLC. v. CEMEX Puerto Rico, Inc. et al
Filing
61
ANSWER to Complaint by CEMEX, CROSSCLAIM against Canopy Ecoterra Corp, COUNTERCLAIM against American Waste Management and Recycling, LLC. filed by Joanne A. Tomasini-Muniz on behalf of Defendants CEMEX Puerto Rico, Inc. Tomasini-Muniz, Joanne) Modified on 10/9/2007 to correct filer. (ft).
American Waste Management and Recycling, LLC. v. CEMEX Puerto Rico, Inc. et al
Doc. 61
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 1 of 35
IN THE UNITED STATES DISTRICT COURT FOR THE DISTRICT OF PUERTO RICO AMERICAN WASTE MANAGEMENT AND RECYCLING, LLC Plaintiff, v. CEMEX PUERTO RICO; ECOTERRA CORP, Defendants. Civil No. 07-01658-JAF Breach of contract; collection of moneys; damages. CANOPY Jury trial demanded.
ANSWER TO VERIFIED COMPLAINT BY DEFENDANT CEMEX DE PUERTO RICO, INC. TO THE HONORABLE COURT: COMES NOW Cemex Puerto Rico, Inc. ("CEMEX"), through its undersigned counsels, respectfully alleges in answer to plaintiff's allegations: JURISDICTION AND VENUE 1. 2. 3. Paragraph 1 is denied for lack of information. Paragraph 2 is denied for lack of information. Paragraph 3 is admitted to the extent that CEMEX de
Puerto Rico, Inc. is a corporation organized under the laws of the Commonwealth of Puerto Rico. 4. 5. 6. Paragraph 4 is admitted. Paragraph 5 is admitted. Paragraph 6 is admitted.
Dockets.Justia.com
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 2 of 35
THE PARTIES 7. Paragraph belief. 8. Paragraph 8 is admitted, with the exception that under no factual or legal basis is Mr. Barsotelli or Canopy 7 is denied due to lack of information and
Ecoterra an agent of CEMEX or should be called as such. 9. Paragraph 9 is admitted, with the exception that under no factual or legal basis is Mr. Barsotelli or Canopy
Ecoterra an agent of CEMEX or should be called as such. 10. Paragraph 10 is admitted to the extent that CEMEX de
Puerto Rico, Inc. is a corporation organized under the laws of the Commonwealth of Puerto Rico. 11. Paragraph 11 is denied. GENERAL ALLEGATIONS 12. Paragraph denied. 13. Paragraph 13 is denied. CEMEX is not privy to the 12 is not an allegation, therefore it is
relationship between AWMR and Canopy Ecoterra. 14. Paragraph 14 is denied. was a party to, the AWMR did not participate in, nor contractual relationship between
CEMEX and Canopy Ecoterra. 14 lack any basis in fact.
The allegations in paragraph
2
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 3 of 35
15.
Paragraph
15
is
denied
for
the
lack
of
direct
information. 16. Paragraph 16 is denied for the lack of direct
information. 17. Paragraph 17 is denied for the lack of direct
information. 18. Paragraph 18 is denied for the lack of direct
information. 19. Paragraph 19 is denied for the lack of direct
information. 20. Paragraph 20 is denied for the lack of direct
information. 21. Paragraph 21 is denied for the lack of direct
information. 22. Paragraph 22 is denied for the lack of direct
information. 23. Paragraph 23 is denied for the lack of direct
information. 24. Paragraph 24 is admitted to the extent that AWMR had the obligation to comply with CEMEX's security policies and to coordinate its dismantling work with CEMEX in order to not interrupt operations at the CEMEX Ponce cement plant.
3
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 4 of 35
25.
Paragraph 25 is denied.
CEMEX learned of the terms of
the agreement between AWMR and Canopy Ecoterra only after the controversy between them arose. 26. Paragraph 26 is admitted solely to the extent it outlines basic procedures to follow in the dismantling and removal of scrap material. Cemex denies any reference to agency
and the remaining allegations contained in the paragraph. 27. Paragraph 27 is denied as redacted. security briefing and I.D.'s to CEMEX provided a personnel, and The are
AWMR
authorized their entrance to the Ponce cement plant. remaining denied. 28. allegations contained in the paragraph
Paragraph 28 is denied for lack of personal knowledge. CEMEX did receive in its cement premises equipment,
trailers and other machinery for AWMR's dismantling and removal services. 29. Paragraph 29 is denied. It is affirmatively alleged that
AWMR engineers and personnel strayed from the work plan authorized by CEMEX, as they would perform dismantling works in unauthorized areas. 30. Paragraph 30 is denied. CEMEX was aware that Canopy
Ecoterra had subcontracted the dismantling and removal of scrap material. CEMEX coordinated the works with Canopy
4
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 5 of 35
Ecoterra's subcontractor, AWMR.
The work to be performed
was in the general areas of kilns 1-4 and mills 2-5, 7 and 10, pursuant to CEMEX's work plan. 31. Paragraph 31 is denied. of CEMEX. Canopy Ecoterra is not an agent
CEMEX did not know terms of the agreement
between AWMR and Canopy Ecoterra because it is not privy to their agreement. and had AWMR AWMR was Canopy Ecoterra's
subcontractor CEMEX, nor
no contractual have to
relationship with any information
did
disclose
regarding its subcontract with Canopy Ecoterra. 32. 33. Paragraph 32 is denied as redacted. Paragraph 33 is denied. It is affirmatively alleged that
CEMEX had a contractual relationship solely with Canopy Ecoterra. 34. Paragraph 34 is denied as drafted. not CEMEX's agent. Canopy Ecoterra is
CEMEX was aware that Canopy Ecoterra
had subcontracted the dismantling and removal of scrap material. coordinating subcontractor, cement plant. 35. Paragraph 35 is denied as drafted. As subcontractor for CEMEX the AWMR, was the sole with to its party interested in
works due
Canopy presence
Ecoterra's within its
the work-execution, AWMR agreed to follow a work plan
5
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 6 of 35
developed by CEMEX in order to prevent any disruption to CEMEX cement plant operations. AWMR strayed from the
execution of the work plan by dismantling and removing materials and equipment not authorized for the particular stage of the work plan. AWMR's actions caused damages to
CEMEX property and, on occasions, interrupted the cement plant operations. 36. Paragraph 36 is denied as drafted. expected AWMR to follow the CEMEX only admits it workplan. CEMEX
affirmatively alleges that the work areas chosen by AWMR were not "optimal" because their location within active plant operations interrupted CEMEX operations, resulting in the interruption of operations and damages to CEMEX property. 37. 38. Paragraph 37 is denied. Paragraph 38 is denied. CEMEX agreed to consider an
amendment to its contract with Canopy Ecoterra only if Canopy Ecoterra could actually show that it suffered
economic losses due to the conditions at the Ponce cement plant. CEMEX did not negotiate with AWMR. Furthermore,
CEMEX learned of the terms of the agreement between AWMR and Canopy Ecoterra only after the controversy between AWMR and Canopy Ecoterra arose.
6
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 7 of 35
39.
Paragraph 39 is denied. of the current Answer
Allegations under paragraph 38 are herby incorporated by
reference. 40. Paragraph 40 is denied. CEMEX only admits that
dismantling and removal works at the CEMEX Ponce cement plant continued until June 22, 2007. 41. Paragraph 41 is denied. CEMEX affirmatively alleges that
the dismantling of facilities built decades ago included dealing with the conditions described by AWMR. conditions, CEMEX. 42. Paragraph 42 is denied as drafted. CEMEX solely admits however, received prompt attention These from
that the asbestos found was promptly removed by Canopy Ecoterra by the end of June, 2007. alleges that asbestos was only CEMEX affirmatively as an isolation
found
material for the power lines that ran close to kilns 1-5. 43. Paragraph 43 is denied. CEMEX affirmatively alleges AWMR
made a proposal for asbestos removal to Canopy Ecoterra. 44. Paragraph 44 is denied. CEMEX affirmatively alleges that
the asbestos was confined to a small area of the plant. During the performance of asbestos removal works, which lasted around six to 8 weeks, AWMR continued (or could
7
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 8 of 35
continue)
works
in
other
parts
of
the
cement
plant
included in the scope of work. 45. 46. Paragraph 45 is denied. Paragraph 46 is denied. "other" AWMR CEMEX CEMEX never offered dismantling CEMEX affirmatively of the and work alleges plan by not
facilities. from the
strayed
execution
dismantling
and
removing
materials
equipment
authorized for the particular stage of the work plan. AWMR's actions caused damages to CEMEX property and
interrupted the cement plant operations. 47. Paragraph 47 is denied as drafted. Before the
controversy between AWMR and Canopy Ecoterra arose, there was no controversy as to `finishing' the project. AWMR
strayed from the appropriate and orderly execution of the work plan, causing damages to CEMEX. CEMEX was not in
agreement with the selective dismantling and removal of metals because the purpose of the contract with Canopy Ecoterra was the complete dismantling and removal of
certain facilities. 48. Paragraph 48 is admitted only to the extent that Ramiro Lozano received the April 26, 2007 letter. The
characterization of facts stated therein is denied.
8
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 9 of 35
49.
Paragraph 49 is denied.
CEMEX affirmatively alleges that
it contracted with Canopy Ecoterra the dismantling and removal of materials in no particular order and that
there were entire areas of the cement plant ready for dismantling, which AWMR refused to work in. 50. Paragraph 50 is admitted only to the extent that AWMR sent the report to CEMEX. stated therein is denied. 51. Paragraph 51 is denied as drafted. alleges Lozano, Abul Mr. Shah attended a CEMEX affirmatively with Mr. Mr. Juan Ramiro Tomás The characterization of facts
meeting and
Ignacio
Barsotelli,
Emmanuelli to discuss the performance of the contract, and AWMR's allegations contained in its April 26, 2007 letter. 52. Paragraph 52 is admitted to the extent that AWMR stated its complaints. under CEMEX paragraph affirmatively 49 of the restates current its
allegations
Answer.
Furthermore, all "live" wires and tubes in use were duly identified by CEMEX personnel before AWMR began work in the designated area, so AWMR could work around them. 53. Paragraph Barsotelli 53 as is denied insofar The they refer to Mr. are
"agent".
remaining
allegations
9
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 10 of 35
denied because they refer to statements in which CEMEX did not participate. 54. Paragraph Barsotelli 54 as is denied insofar The they refer to Mr. are
"agent".
remaining
allegations
denied because they refer to statements in which CEMEX did not participate. Furthermore has reason to believe
AWMR did make a proposal for asbestos removal to Canopy Ecoterra. 55. Paragraph 55 is denied as drafted. part of his for duties, asbestos Mr. CEMEX admits that as Lozano requested various
Ramiro
quotations providers. 56.
removal
services
from
Paragraph 56 is admitted in so far as asbestos removal service providers came to the plant to inspect and make proposals.
57.
Paragraph 57 is denied for lack of direct information; it refers to events in which CEMEX did not participate Mr. Barsotelli is not an "agent" of CEMEX.
58.
Paragraph 58 is denied for lack of direct information; it refers to events in which CEMEX did not participate. Barsotelli is not an "agent" of CEMEX. Mr.
59.
Paragraph 59 is denied for lack of direct information; it refers to events in which CEMEX did not participate.
10
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 11 of 35
60.
Paragraph 60 is denied for lack of direct information; it refers to events in which CEMEX did not participate.
Mr. Barsotelli is not an "agent" of CEMEX. 61. 62. Paragraph 61 is denied. Paragraph 62 is denied for lack of direct information; it refers to events in which CEMEX did not participate. 63. Paragraph 63 is denied as drafted. it approved the removal of CEMEX solely admits the remaining
asbestos,
allegations are denied. not "agents" of CEMEX. 64.
Canopy and Mr. Barsotelli are
Paragraph 64 is denied because it refers to events in which CEMEX did not participate. an "agent" of CEMEX. Mr. Barsotelli is not
65.
Paragraph 65 is denied because it refers to events in which CEMEX did not participate.
66.
Paragraph 66 is denied because it refers to events in which CEMEX did not participate.
67.
Paragraph 67 is denied because it refers to events in which CEMEX did not participate.
68.
Paragraph
68
is and
denied
because between
it
refers
to
communications
obligations
Canopy
Ecoterra
and its subcontractor, AWMR.
11
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 12 of 35
69.
Paragraph
69
is and
denied
because between
it
refers
to
communications
obligations
Canopy
Ecoterra
and its subcontractor, AWMR. 70. 71. Paragraph 70 is denied. Paragraph 71 is denied because it refers to events in which CEMEX did not participate, or to issues in which CEMEX has no basis to allege. 72. Paragraph 72 is denied because it refers to events in which CEMEX did not participate, or to issues in which CEMEX has no basis to allege. 73. Paragraph 73 is denied because it refers to events in which CEMEX did not participate, or to issues in which CEMEX has no basis to allege. 74. Paragraph 74 is denied because it refers to events in which CEMEX did not participate, or to issues in which CEMEX has no basis to allege. 75. Paragraph 75 is denied because it refers to events in which CEMEX did not participate, or to issues in which CEMEX has no basis to allege. 76. Paragraph 76 is denied because it refers to events in which CEMEX did not participate, or to issues in which CEMEX has no basis to allege.
12
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 13 of 35
77.
Paragraph 77 is denied; CEMEX personnel have no knowledge of `locks being cut'. CEMEX affirmatively alleges that
AWMR acquiesced to the removal of a container by Ignacio Barsotelli because an AWMR engineer aided Mr. Barsotelli in the removal of the container. 78. 79. Paragraph 78 is denied. Paragraph 79 is denied. CEMEX's "General Services
Coordinator" was designated to authorize the removal of containers from CEMEX's Ponce cement plant premises. He
did not authorize the way-bill because it did not have a destination. 80. 81. Paragraph 80 is denied. Paragraph 81 does not require an allegation from CEMEX, for which reason it is denied. 82. Paragraph 82 does not require an allegation from CEMEX, for which reason it is denied. 83. Paragraph 83 is denied as drafted. Mr. Ramiro Lozano and
Mr. Juan Emmanuelli intervened in an attempt to aid the parties in amicably resolving the controversy. 84. Paragraph 84 is denied as drafted. CEMEX only intervened
in an attempt to aid the parties in amicably resolving the controversy. AWMR; it only CEMEX did not reach any agreement with attempted to mediate the controversy
13
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 14 of 35
between
AWMR
and
Canopy
Ecoterra
in
order
to
secure
timely completion of the project. 85. 86. Paragraph 85 is denied. Paragraph 86 is denied because it refers to events
between Canopy Ecoterra and AWMR. an "agent" of CEMEX. 87. CEMEX admits a paragraphs matter to 87 the to
Mr. Barsotelli is not
the
extent
that
AWMR the
referred
police
authorities;
remaining allegations are denied for lack of information. 88. CEMEX admits a paragraphs matter to 88 the to the extent that AWMR the
referred
police
authorities;
remaining allegations are denied for lack of information. 89. Paragraph 89 is denied insofar it assumes that CEMEX was in a position to adjudicate the controversy between
Canopy Ecoterra and its subcontractor, AWMR. 90. 91. Paragraph 90 is denied. Paragraph 91 is denied. of CEMEX. 92. Paragraph 92 does not require a responsive pleading from Cemex and therefore is denied. 93. Paragraph 93 does not require a responsive pleading from Cemex and therefore is denied. Mr. Barsotelli is not an "agent"
14
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 15 of 35
94.
Paragraph 94 does not require a responsive pleading from Cemex and therefore is denied.
95.
Paragraph 95 does not require a responsive pleading from CEMEX and therefore is denied.
96.
Paragraph 96 does not require a responsive pleading from CEMEX and therefore is denied. Neither Mr. Barsotelli
nor Canopy Ecoterra is an "agent" of CEMEX. 97. Paragraph 97 does not require a responsive pleading from CEMEX and therefore is denied. 98. Paragraph 98 does not require a responsive pleading from CEMEX and therefore is denied. 99. Paragraph 99 is denied. smooth transition in CEMEX solely admits it sought a work being performed in its
the
cement facilities. 100. Paragraph alleges 100 is admitted sought a only to the extent in that it the work
CEMEX
smooth
transition
being performed in its cement facility; the remainder of the allegations is denied. 101. Paragraph 101 is admitted solely to the extent that a loading dock was built during the month of 2007, the
remaining allegations are denied.
15
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 16 of 35
102. Paragraph 102 is admitted only to the effect that AWMR continued some removal of metals, the remaining
allegations are denied. 103. Paragraph 103 is denied as drafted; CEMEX solely admits that certain containers were registered pursuant to CEMEX standard procedures. 104. Paragraph 104 is denied as drafted; it does not provide a time frame accurate Mr. enough to is allow not is a an responsive "agent" of
allegation. CEMEX.
Barsotelli
105. Paragraph 105 is denied as drafted; it does not provide a time frame accurate enough to allow a responsive
allegation. 106. Paragraph 106 is denied as drafted; it does not provide a time frame accurate enough to allow a responsive
allegation. 107. Paragraph 107 is denied. 108. Paragraph 108 is admitted only to the extent that on June 22, 2007 a CEMEX issued the letter. The remaining
allegations are denied. 109. Paragraph 109 is denied. 110. Paragraph 110 is denied. 111. Paragraph 111 is denied.
16
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 17 of 35
112. Paragraph 112 is denied. 113. Paragraph 113 is denied. 114. Paragraph that it 114 is denied. to protect CEMEX its affirmatively interests alleges the
tried
given
increasingly tense situation between Canopy Ecoterra and AWMR. 115. Paragraph that it 115 is denied. to protect CEMEX its affirmatively interests alleges the
tried
given
increasingly tense situation between Canopy Ecoterra and AWMR. 116. Paragraph that it 116 is denied. to protect CEMEX its affirmatively interests alleges the
tried
given
increasingly tense situation between Canopy Ecoterra and AWMR. 117. Paragraph that it 117 is denied. to protect CEMEX its affirmatively interests alleges the
tried
given
increasingly tense situation between Canopy Ecoterra and AWMR. 118. Paragraph that it 114 is denied. to protect CEMEX its affirmatively interests alleges the
tried
given
increasingly tense situation between Canopy Ecoterra and AWMR.
17
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 18 of 35
119. Paragraph 119 is admitted.
The characterization of the
instruction as "sudden" is denied. 120. Paragraph 120 is admitted. that it allowed AWMR CEMEX affirmatively alleges time to secure all
personnel
equipment, trailers, and containers in the site. 121. Paragraph 121 is denied. 122. Paragraph 122 is denied. 123. Paragraph 123 is denied. 124. Paragraph 124 is denied. CEMEX affirmatively alleges that it allowed AWMR personnel time to secure all equipment, trailers, and containers in the site. 125. Paragraph 125 is denied. 126. Paragraph 126 is denied. 127. Paragraph 127 is denied. 128. Paragraph 128 is denied. 129. Paragraphs 129-130 do not require responsive pleading
from CEMEX and are therefore denied. 130. Paragraph 131 is denied. 131. Paragraph 132 is denied. 132. Paragraph 133 is denied. 133. Paragraph 134 is denied. 134. Paragraph 135 is denied. 135. Paragraph 136 is denied.
18
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 19 of 35
136. Paragraph 137 is denied. 137. Paragraph 138 is denied. 138. Paragraph 139 is denied. 139. Paragraph 140 is denied. 140. Paragraph 141 is denied. FIRST CAUSE OF ACTION 141. Paragraphs 142-152 are denied. AWMR had a contractual Neither of
relationship with Canopy Ecoterra exclusively. Mr. Barsotelli nor Canopy Ecoterra is an
"agent"
CEMEX.
Any claim of contractual rights and obligations It is frivolous to as an agent of
between CEMEX and AWMR is frivolous. allege CEMEX. SECOND CAUSE OF ACTION 142. Paragraphs 153-163 are denied. THIRD CAUSE OF ACTION 143. Paragraph denied. 144. Paragraphs 165-169 are denied. 164 is not an allegation, and designate Canopy
Ecoterra
therefore
it
is
Furthermore, they do not
require a responsive pleading from CEMEX. FOURTH CAUSE OF ACTION 145. Paragraph denied. 170 is not an allegation, therefore it is
19
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 20 of 35
146. Paragraph
171
is
denied.
Furthermore,
it
does
not
require a responsive pleading from CEMEX. FIFTH CAUSE OF ACTION 147. Paragraph denied. 148. Paragraphs 173-174 are denied. Furthermore, they do not 172 is not an allegation, therefore it is
require a responsive pleading from CEMEX. SIXTH CAUSE OF ACTION 149. Paragraph denied. 150. Paragraphs 176-182 are denied. RELIEF SOUGHT 151. Paragraph denied. 152. Paragraphs 184-190 are denied. 183 is not an allegation, therefore it is 175 is not an allegation, therefore it is
AFFIRMATIVE DEFENSES FOR DEFENDANT CEMEX DE PUERTO RICO, INC.'S 1. 2. 3. Unclean hands. Estoppel. Plaintiff's claims against CEMEX are frivolous; they
assume a contractual relationship with CEMEX knowing it has never existed.
20
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 21 of 35
4.
AWMR was subcontracted by Canopy Ecoterra to remove all metals and materials from the site. In selecting the
most valuable materials to remove, AWMR was setting the stage to default in its obligations. 5. AWMR, allegedly an expert in dismantling metals and
removal of scrap metal materials, knew or should have known of the possibility of the presence of materials such as asbestos, of the presence of live electric wires, and of water lines, especially since the work to be
executed would take place inside an active cement plant. 6. AWMR strayed from and the execution of the and work plan by not
dismantling
removing
materials
equipment
authorized for the particular stage of the work plan. AWMR's actions caused damages to CEMEX property and, on occasions, interrupted the cement plant operations. 7. AWMR acted in bad faith by creating Ponce a hostile plant, work by
environment
within
CEMEX's
cement
involving CEMEX in controversies between Canopy Ecoterra and AWMR, by spreading false rumors involving CEMEX and CEMEX employees, and by including CEMEX in this frivolous complaint. CEMEX DE PUERTO RICO'S COUNTER AND CROSS CLAIMS I. GENERAL FACTUAL ALLEGATIONS APPLICABLE TO ALL OF CEMEX'S CAUSES OF ACTION:
21
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 22 of 35
1. negotiated
During
the
summer
of
2006, and
CEMEX
de
Puerto to
Rico
certain
agreements
acquiesced
various
obligations regarding its operations in the Municipality of Ponce, Puerto Rico. 2. The Municipality of Ponce, various neighborhood
associations, and CEMEX reached certain compromises regarding the investment to of capital and the incorporation Cement of new and
technologies
modernize
CEMEX's
Ponce
Plant
promote increased environmental standards. 3. However, CEMEX to implement to the modern processes and
operations,
needed
dismantle
obsolete
parts,
equipment or machinery of its plant, including mills, kilns, and secondary are equipment, within like the precipitators plant's active form and and chimneys. operating of the
These
located and
structures
equipments
because
they
part
originally built cement plant. 4. With a particular time frame agreed upon with the
Municipality of Ponce, CEMEX requisitioned the dismantling and removal project. disassembly and CEMEX's only interest in the project was the removal of the plant's machinery and
structures not in use. 5. companies. CEMEX was able to obtain quotations from different However, most project proposals received by CEMEX
22
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 23 of 35
required
some
sort of disbursement
or deposit by CEMEX
in
order to execute the project. 6. more Because the scrap material to be removed is worth the actual performance of the project, CEMEX
than
representatives required a contract at no cost or at a benefit for CEMEX, without any initial disbursement or deposit. 7. Canopy Eventually Mr. Ignacio Barsotelli and his company, Ecoterra, accepted a contract without an initial
deposit or disbursement by CEMEX.
CEMEX and Canopy Ecoterra
agreed that Canopy Ecoterra would pay CEMEX $23.00 per ton of scrap material dismantled and removed from the Ponce cement plant. 8. Around and August Sale of 2006, Scrap the "Contract for the de
Dismantling
Material"
("Contrato
Desmontaje y Venta de Chatarra") (hereinafter, "Contract") was formally executed between CEMEX and Canopy Ecoterra. 9. executed project Although the Contract has no date, the Contract was before manager, the scope of work was drafted by CEMEX's by the
José
Manuel
Fraticelli,
approved
General Cement Plant Manager on September 15, 2006. 10. On or around that date, Canopy Ecoterra and CEMEX
incorporated the scope of work to the Contract.
23
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 24 of 35
11.
Through
information
and
belief,
Canopy
Ecoterra
subcontracted its rights under the Contract to at least two different subcontractors that performed works before Canopy
Ecoterra subcontracted its rights under the Contract to AWMR. 12. CEMEX also in worked with Canopy of Ecoterra's works to other prevent
subcontractors
the
coordination
interruptions in plant operations. 13. CEMEX did not participate in any contracts executed CEMEX was not
between Canopy Ecoterra and its subcontractors. privy to the subcontract. 14. Canopy Ecoterra subcontracted
American
Waste
Management & Recycling ("AWMR") to perform the Contract in March 29, 2007. 15. CEMEX did not participate in the contract executed CEMEX was not
between American Waste and Canopy Ecoterra. privy to the subcontract. 16.
Canopy Ecoterra and AWMR visited and inspected the Through information
plant before subscribing the contract.
and belief, CEMEX affirmatively alleges that AWMR accepted the subcontract in an "as is" condition. 17. CEMEX of and works AWMR to only prevent worked jointly in in the plant
coordination operations.
interruptions
24
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 25 of 35
18.
CEMEX's only interest was the timely performance by
Canopy Ecoterra of the project of dismantling and removing the items listed in the September 15, 2006 Scope of Work. 19. CEMEX representatives did not receive or review the
agreement between Canopy Ecoterra and AWMR. 20. CEMEX had no interest in whether Canopy Ecoterra
subcontracted or not the services required in the project. 21. CEMEX's only interest was that at the cost of Canopy
Ecoterra and in the period of one year, the works at the Ponce plant would be finished; the intact and adequately functioning facilities would have had no obsolete and unwanted material, equipment or structures. 22. Not until after the subcontract had been executed
and the controversies regarding its specific performance arose between our contractor, Canopy Ecoterra, and its
subcontractor, did CEMEX even review the subcontract. 23. In order to organize the execution the dismantling
works in a way to least interrupt CEMEX's operations, Jose Manuel Fraticelli developed a work plan with Canopy Ecoterra's subcontractors, AWMR. 24. As subcontractor for the work-execution, AWMR agreed
to follow a work plan orally agreed upon in order to prevent any disruption to CEMEX cement plant operations.
25
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 26 of 35
25.
AWMR,
however,
strayed
from
the
execution
of
the
work plan by dismantling and removing materials and equipment not authorized for the particular stage of the work plan. 26. plant AWMR worked in unauthorized areas within the active in order to harvest specific material,
operations
considered to be more valuable.
These acts interrupted CEMEX
operations and caused damages to CEMEX property. 27. From early on in the performance of its subcontract,
AWMR unreasonably claimed it was unable to properly perform the contract. 28. On April 26, 2007, AWMR sent a letter to Mr. Ramiro
Lozano listing certain conditions in the Ponce facilities that allegedly impeded or delayed the removal of metals. 29. issues As a result, CEMEX held a meeting to discuss the between CEMEX and Canopy's subcontractor's poor
performance of the contract. 30. structure, Canopy and location its and subcontractor operations alleged that CEMEX's were such, that the
dismantling cost was too high.
As a result, CEMEX, in good
faith agreed to consider an amendment to its contract with Canopy Ecoterra, only if Canopy Ecoterra could affirmatively show that it suffered economic losses due to the conditions at the Ponce cement plant.
26
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 27 of 35
31.
CEMEX
never
reached
an
agreement
to
amend
the
Contract with Canopy Ecoterra. 32. Furthermore, CEMEX never directly negotiated with
AWMR any amendment to CEMEX's Contract. intend to. 33.
Nor did CEMEX ever
On the contrary, AWMR continuously approached CEMEX
representatives with unwanted offers regarding their capacity of performing the project, if directly engaged by CEMEX. 34. As time passed there were rumors that Canopy
Ecoterra and AWMR were having problems regarding the terms and conditions of their agreement. picking," valuable i.e. selectively Through Apparently AWMR was "cherryand and removing belief, only Canopy
dismantling information
material.
Ecoterra thought it unwarranted. 35. informed Through AWMR it information would not and belief, Canopy Ecoterra or the
tolerate
cherry-picking
selective removal of valuable material, and as such requested AWMR to abstain from removing only valuable materials. 36. Shah and On Memorial Day, May 28, 2007, at 1:04pm, Mr. Abul his driver personally removed a copper-filled
container, after Canopy Ecoterra expressly requested that AWMR abstain from exclusively removing valuable materials.
27
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 28 of 35
37.
Afterwards,
in
the
presence
of
one
of
AWMR's
engineers assigned to the project, Canopy Ecoterra, through Ignacio material. 38. Julio Mateo, the CEMEX employee in charge of Barsotelli, removed two or three containers of
authorizing way bills, never authorized removal of the three containers destination. 39. A controversy arose between Canopy Ecoterra and AWMR AWMR alleged it in those because Canopy Ecoterra had not identified a
regarding the containers removed by Ecoterra. dismantled, gathered and loaded the
material
containers, and as such it was their property. 40. Given the ensuing controversy and AMWR's frivolous
threats of filing criminal charges, CEMEX intervened in an attempt to resolve amicably and efficiently the controversy. 41. Such an action became necessary for CEMEX because
both AWMR and Canopy Ecoterra principals were unwilling even to meet face to face and negotiate; and any delay in the performance of the project would compromise CEMEX's capacity to comply with the agreements it had reached with the
Municipality of Ponce and other organizations. 42. In order to mitigate potential damages from the
conflict between contractor and subcontractor, CEMEX urged the
28
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 29 of 35
parties to continue performing their contracts and to try and reach some sort of solution. 43. However, grew the to controversy such an between that contractor it and
subcontractor
extent
eventually
affected the timely performance of the work-execution project that CEMEX needed completed in the period of one year. 44. CEMEX only tried to protect its interests given the
increasingly tense situation between Canopy Ecoterra and AWMR. 45. AWMR contributed to the polarization of the
situation through Mr. Abul Shah's threats of civil litigation and criminal prosecution against Canopy Ecoterra. AWMR's sole interest was directly engaging CEMEX His and in the
dismantling and removal project. 46. worsened, Through AWMR information expressed and belief, in as the situation Canopy
interest
purchasing
Ecoterra's rights under the Contract with CEMEX, but Canopy refused to sell. 47. The situation reached a point where it became
apparent that Mr. Abul Shah's threats of civil litigation and criminal prosecution against both Canopy Ecoterra and CEMEX only responded to his interest in CEMEX's termination of its contract with Canopy Ecoterra, and the direct engagement of AWMR's services.
29
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 30 of 35
48.
Mr. Shah even represented that he would forget about
his claims regarding the alleged stolen property, in exchange for CEMEX's direct engagement of AWMR. 49. Finally, Mr. Abul Shah's threats of criminal
investigation became a reality:
AWMR filed a formal complaint
for criminal investigation against Canopy Ecoterra with the Puerto Rico police. 50. Given the polarity of the situation and AWMR's
insistence in frivolously threatening to sue CEMEX unless they were directly engaged to perform the project, on June 22, 2007 CEMEX ordered Canopy Ecoterra to cease all works and services within the premises of the company. 51. That same day, CEMEX personnel requested AWMR AWMR
personnel to cease operations and vacate the premises.
personnel were allowed to clear up and secure its property before leaving the premises. Once AWMR personnel left the
premises, CEMEX assigned 24 hour security to the facilities in order to specifically guard the property. 52. At that date, only fifteen to twenty percent (15-
20%) of the dismantling works had been performed. II. CEMEX DE PUERTO RICO'S FIRST CAUSE OF ACTION: BREACH OF CONTRACT.
30
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 31 of 35
53. the
Canopy Ecoterra's subcontractor, AWMR, strayed from and orderly execution of the work plan,
appropriate
causing damages to CEMEX. 54. property Canopy Ecoterra's subcontractor, AWMR, broke CEMEX in use, such as floors, safety rails, and water
lines, disconnected water recirculation pumps and wells. 55. property Subcontractor AWMR's actions caused damages to CEMEX and interrupted the cement plant operations on
multiple occasions. 56. The interruptions in operations resulted in a loss
of nearly 400 tons of packed cement and in bulk. 57. Furthermore, under the Contract, Canopy Ecoterra
agreed to finalize the project in the period of one year. 58. Due to the internal controversies regarding its
subcontractor, and Canopy Ecoterra's poor work-execution, the Contract was not timely performed. 59. resulted The in delay severe in the termination damages that of the contract to be
economic
have
yet
quantified by CEMEX. 60. The delay in the termination of the Contract has
exposed CEMEX to liability before Commonwealth of Puerto Rico and U.S. federal government administrative agencies, such as the U.S. Environmental Protection Agency and the P.R.
31
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 32 of 35
Environmental Quality Board that has yet to be quantified by CEMEX. 61. The delay in the termination of the Contract has
resulted in exposure to liability for non compliance with its informal agreements with the Municipality of Ponce and
neighborhood associations. III. CEMEX DE PUERTO RICO'S SECOND CAUSE OF ACTION: INTENTIONAL INTERFERENCE WITH CONTRACT. 62. AWMR intentionally created a hostile work
environment within CEMEX's Ponce cement plant. 63. AWMR intentionally an in bad faith involved CEMEX in
controversies between Canopy Ecoterra and AWMR, by spreading false rumors involving CEMEX and CEMEX employees, and by
including CEMEX in this frivolous complaint. 64. AWMR purposefully with its contract access to extended party, CEMEX and Canopy polarized Ecoterra, in
disagreements order to
gain direct
management
and force
CEMEX to completion of the Contract with Canopy Ecoterra. 65. AWMR exacerbated any and all controversies with
Canopy Ecoterra, frivolously involving CEMEX, with the sole purpose of having CEMEX directly engage AWMR for the execution of the dismantling and removal project. 66. AWMR's actions forced CEMEX to stay the work
execution, and the corresponding delay in the termination of
32
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 33 of 35
the
Contract. for
As all
such, damages
it
is
jointly from
and the
severally contractual
responsible breach. IV.
resulting
CEMEX DE PUERTO RICO'S THIRD CAUSE OF ACTION: DAMAGES FOR LOSS OF REPUTATION. 67. AWMR intentionally created a hostile work
environment within CEMEX's Ponce cement plant. 68. AWMR intentionally an in bad faith involved CEMEX in
controversies between Canopy Ecoterra and AWMR, by spreading false rumors involving CEMEX and CEMEX employees, and by
including CEMEX in this frivolous complaint. 69. AWMR's actions have caused damages to CEMEX's name
and reputation, because it is now unable to timely finalize the project, exposing CEMEX to liability before Commonwealth of Puerto Rico and U.S. government administrative agencies, and forcing CEMEX to renege on its informal agreements with the Municipality of Ponce and neighborhood associations. V. REQUEST FOR SANCTIONS: The Court should find that AWMR has acted without any regard to applicable law by (i) artificially designating
Canopy Ecoterra and agent of CEMEX, being fully aware of the contractual relationship between parties; (ii) requesting
equitable relief without basis for such remedy because there
33
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 34 of 35
is
no
irreparable damage in this available, and there is
case, no
there clear
are
adequate of
remedies
likelihood
prevailing on the merits; (iii) making a series of completely unfounded allegations. So clear is the lack of any evidence whatsoever of any contractual relation between AWMR and CEMEX, that AWMR's
decision to file the above captioned Complaint and request preliminary injunctive relief, should be held to have been frivolous. this Court As a result, upon conclusion of this litigation, should order AWMR to show cause why sanctions
should not be imposed upon it. See, e.g., 28 U.S.C. § 1927; see also Chambers v. NASCO, Inc., 501 U.S. 32 (1991). WHEREFORE, respectfully frivolous defendant this CEMEX de Puerto Court grant to the Rico, Inc., the
requests
Honorable by AWMR,
dismiss
complaint
filed
counterclaim
against AWMR and the cross-claim against Canopy Ecoterra filed by CEMEX on this day including compensation of all damages suffered finished. in an amount to be determined once discovery is
CEMEX further requests this Honorable Court grant
attorneys fees, sanctions and any other remedy available at law in favor of CEMEX. RESPECTFULLY SUBMITTED.
34
Case 3:07-cv-01658-JAF
Document 61
Filed 10/05/2007
Page 35 of 35
I HEREBY CERTIFY that today I electronically filed the foregoing with the Clerk of the Court using CM/ECF system
which will send notification of such filing to all counsel of record. In San Juan, Puerto Rico, this 5th day of October, 2007. /s/Jaime E. Toro-Monserrate_ Jaime E. Toro-Monserrate USDC-PR No. 204,601 jetoro@tcmrslaw.com /s/Joanne A. Tomasini-Muñiz_ Joanne A. Tomasini-Muñiz USDC-PR No. 218,809 jtomasini@tcmrslaw.com TORO, COLÓN, MULLET, RIVERA & SIFRE, P.S.C. Attorneys for defendant, CEMEX de Puerto Rico, Inc. PO Box 195383 San Juan, PR 00919-5383 Tel: (787) 751-8999 Fax: (787) 763-7760
35
Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.
Why Is My Information Online?