Constitution Pipeline Company, v. New York State Department of E


OPINION, petition dismissed in part and denied in part, by ALK, RCW, CFD, FILED.[2103921] [16-1568]

Download PDF
Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page1 of 27 16-1568 Constitution Pipeline Co. v. New York State Department of Environmental Conservation 1 UNITED STATES COURT OF APPEALS 2 FOR THE SECOND CIRCUIT 3 ------ 4 August Term, 2016 5 (Argued: November 16, 2016 6 Decided: August 18, 2017) Docket No. 16-1568 7 _________________________________________________________ 8 CONSTITUTION PIPELINE COMPANY, LLC, 9 Petitioner, 10 - v. - 11 12 13 14 NEW YORK STATE DEPARTMENT OF ENVIRONMENTAL CONSERVATION; BASIL SEGGOS, Acting Commissioner, New York State Department of Environmental Conservation; JOHN FERGUSON, Chief Permit Administrator, New York State Department of Environmental Conservation, 15 Respondents, 16 17 STOP THE PIPELINE, CATSKILL MOUNTAINKEEPER, INC., SIERRA CLUB, RIVERKEEPER, INC., 18 19 Intervenors.* _________________________________________________________ 20 Before: KEARSE, WESLEY, and DRONEY, Circuit Judges. 21 Petition for review of respondents' decision denying application for certification * The Clerk of Court is directed to amend the official caption to conform with the above. Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page2 of 27 1 pursuant to § 401 of the Clean Water Act, 33 U.S.C. § 1341, that petitioner's proposed interstate 2 natural gas pipeline would comply with New York State water quality standards ("§ 401 3 certification"). Respondents denied the application on the ground that petitioner had not complied 4 with requests for relevant information. Petitioner contends (1) that respondents exceeded the statutory 5 time limitations for the State's review of the application and that they must therefore be ordered to 6 notify the United States Army Corps of Engineers ("USACE") that the State waives its right to issue 7 or deny § 401 certification, thereby allowing USACE to issue a permit to petitioner under § 404 of 8 the Clean Water Act, see 33 U.S.C. § 1344(a); and (2) alternatively, that respondents' decision should 9 be vacated on the ground that the denial of the application was arbitrary, capricious, and ultra vires, 10 and that respondents should be ordered to grant the requested § 401 certification. To the extent that 11 petitioner challenges the timeliness of respondents' decision, we conclude that we lack jurisdiction 12 over that challenge. As to the merits, we conclude that respondents' actions were within their 13 statutory authority and that the decision was not arbitrary or capricious. 14 Petition dismissed in part and denied in part. 15 16 17 18 JOHN F. STOVIAK, Philadelphia, Pennsylvania (Saul Ewing, Philadelphia, Pennsylvania, Elizabeth Utz Witmer, Saul Ewing, Wayne, Pennsylvania; Yvonne E. Hennessey, Barclay Damon, Albany, New York, on the brief), for Petitioner. 19 20 21 22 23 24 BRIAN LUSIGNAN, Assistant Attorney General, Albany, New York (Eric T. Schneiderman, Attorney General of the State of New York, Barbara D. Underwood, Solicitor General, Andrew B. Ayers, Senior Assistant Solicitor General, Frederick A. Brodie, Assistant Solicitor General, Lisa M. Burianek, Deputy Bureau Chief, Albany, New York, on the brief), for Respondents. 2 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page3 of 27 1 2 3 4 KARA E. PAULSEN**, White Plains, New York (Karl S. Coplan, Todd D. Ommen, Anne Marie Garti, Pace Environmental Litigation Clinic, Inc., White Plains, New York, on the brief), for Intervenor Stop the Pipeline. 5 6 7 8 MONEEN NASMITH, New York, New York (Deborah Goldberg, Christine Ernst, Earthjustice, New York, New York, on the brief), for Intervenors Catskill Mountainkeeper, Inc., Sierra Club, and Riverkeeper, Inc. 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 SIDLEY AUSTIN, Washington, D.C. (Roger R. Martella, Jr., Ryan C. Morris, Tobias S. Loss-Eaton, Washington, D.C.; Linda E. Kelly, Quentin Riegel, Leland P. Frost, Manufacturers' Center For Legal Action, Washington, D.C.; Steven P. Lehotsky, Sheldon B. Gilbert, U.S. Chamber Litigation Center, Washington, D.C.; Kevin B. Belford, Michael L. Murray, Washington, D.C.; Leslie A. Hulse, Washington, D.C.; Dena E. Wiggins, Washington, D.C.; Andrea J. Chambers, Katie Leesman, Ballard Spahr, Washington, D.C., of counsel), filed a brief for Amici Curiae National Association of Manufacturers, Chamber of Commerce of the United States of America, Interstate Natural Gas Association of America, American Gas Association, American Petroleum Institute, American Chemistry Council, Natural Gas Supply Association, American Forest & Paper Association, and Process Gas Consumers Group, in support of Petitioner. 25 26 27 28 29 Kimberly Ong, New York, New York (Albert K. Butzel, New York, New York, of counsel), filed a brief for Amici Curiae Natural Resources Defense Council, Water Defense, Waterkeeper Alliance, Earthworks, PennEnvironment, Peconic Baykeeper, and Chesapeake Bay Foundation, in support of Respondents. 30 KEARSE, Circuit Judge: 31 Petitioner Constitution Pipeline Company, LLC ("Constitution"), petitions pursuant 32 to 15 U.S.C. § 717r(d)(1) for review of an April 22, 2016 decision of the New York State Department 33 of Environmental Conservation ("NYSDEC" or the "Department") denying Constitution's application ** Law student appearing pursuant to Local Rule 46.1(e). 3 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page4 of 27 1 for certification pursuant to § 401 of the Federal Water Pollution Control Act, more commonly known 2 as the Clean Water Act (or "CWA"), 33 U.S.C. § 1341 ("§ 401 certification"), that Constitution's 3 proposed interstate natural gas pipeline would comply with New York State (or "State") water quality 4 standards (or "WQS"). NYSDEC denied the application on the ground that Constitution had not 5 provided sufficient information. In its petition, Constitution contends principally (1) that NYSDEC 6 exceeded the § 401(a) time limitations for the State's review of the application and that NYSDEC 7 must therefore be ordered to notify the United States Army Corps of Engineers ("USACE" or "Army 8 Corps of Engineers" or "Army Corps") that the State has waived its right to act upon Constitution's 9 § 401 certification application, thereby allowing USACE to issue a permit to petitioner under § 404 10 of the Clean Water Act, see 33 U.S.C. § 1344(a); and (2) alternatively, that Constitution submitted 11 sufficient information and that NYSDEC's decision should be vacated on the ground that its denial 12 of the application was arbitrary, capricious, and ultra vires, and that NYSDEC should be ordered to 13 grant the requested § 401 certification. To the extent that Constitution challenges the timeliness of 14 the NYSDEC decision, we dismiss the petition for lack of jurisdiction. As to the merits, we conclude 15 that NYSDEC's actions were within its statutory authority and that its decision was not arbitrary or 16 capricious, and we deny the petition. 17 I. BACKGROUND 18 Constitution proposes to construct a 121-mile interstate natural gas pipeline in 19 Pennsylvania and New York, approximately 98 miles of which would be in New York. In connection 20 with this project (the "Project"), Constitution applied for, to the extent pertinent here, a "certificate 4 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page5 of 27 1 of public convenience and necessity" from the Federal Energy Regulatory Commission ("FERC"), 2 15 U.S.C. § 717f(c), a CWA § 401 water quality certification (or "WQC") from New York State that 3 the Project would comply with State water quality standards (see 6 N.Y.C.R.R. parts 701 to 704), and 4 a CWA § 404 permit from the Army Corps of Engineers to allow discharges into United States 5 navigable waters. 6 A. Proceedings Before FERC 7 In September 2012, FERC announced that it would prepare an environmental impact 8 statement ("EIS") for Constitution's Project and asked Constitution to submit a feasibility study 9 explaining how it would install the pipeline across waterbodies (generally using that term to refer to 10 streams but not wetlands). For such installations, there is a trenched method--a dry open-cut crossing- 11 -which involves diverting a stream, digging a trench through the banks and stream bed, installing and 12 burying the pipeline, and then allowing the stream to resume flowing in the stream bed. (See, e.g., 13 FERC Final Environmental Impact Statement ("FEIS") pages 2-21 to 2-22.) There are also trenchless 14 crossing methods--including Horizontal Directional Drill (or "HDD"), Direct Pipe (or "DP"), and 15 conventional bore--which involve digging pits on either side of a waterbody and boring or drilling 16 underneath the stream. FERC asked Constitution to provide information with regard to trenchless 17 construction methods for crossing several categories of streams, including those classified by the 18 states as sensitive or high quality and those greater than 30 feet wide where a dry construction method 19 would not be feasible. 5 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page6 of 27 1 1. Constitution's Trenchless Feasibility Study 2 Constitution submitted to FERC a study discussing trenchless crossing methods. (See 3 Constitution, Feasibility Study: Trenchless Construction Methods for Sensitive Environmental 4 Resource Crossings (Nov. 2013) ("Constitution 2013 Feasibility Study" or "Study") pages 1-3 to 1-5.) 5 Trenchless methods do not disturb soil or organisms in the stream banks, stream bed, or in the stream 6 itself, but require disturbing surrounding areas to clear space for installation pits; there are also risks 7 of mid-project drill breakage, with leakage of drill fluid into the waterbody. (See Constitution 2013 8 Feasibility Study page 2-3; FEIS page 2-24.) Use of the trenched method does not require as much 9 installation space or present the risk of drill failure; but it requires stream diversion and digging into 10 the stream bed and banks. (See, e.g., FEIS pages 2-21 to 2-22.) 11 The Constitution feasibility study dealt principally with locations where the waterbody 12 was designated by New York or Pennsylvania as sensitive or high quality. (See Constitution 2013 13 Feasibility Study pages 2-2 to 2-3.) As a result, Constitution eliminated from consideration for 14 trenchless crossings all but 89 of the 251 New York waterbodies that would be crossed by the pipeline 15 or affected by pipeline construction. 16 The remaining 89 locations were addressed in three phases. The Study's "Phase I[] 17 Desktop Analysis" (id. pt. 1.0 page 1-1) further reduced the number of New York waterbodies 18 considered by Constitution for trenchless crossings from 89 to 26, in part by eliminating streams less 19 than 30 feet wide, even if they were classified by New York as sensitive or high-quality (see id. pages 20 2-1, 2-3). Constitution stated that trenchless crossings for such narrower waterbodies would 21 potentially require workspace requirements significantly greater than those generally needed for a 22 conventional dry crossing method. (See id. page 2-3.) Thus, unless such a waterbody was 6 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page7 of 27 1 immediately associated with a larger wetland and/or waterway complex crossed by the Project or was 2 located in the immediate vicinity of a proposed rail or roadway crossing, "Constitution did not 3 evaluate waterbody crossings less than 30 feet in width" (id.). 4 Phase II was a "Cost/Time/Construction Workspace Impact Analysis." (Id. page 3-1; 5 see also id. pt. 1.0 page 1-1 ("Trenchless construction methods are limited" not only by such matters 6 as "underlying geology, available workspace, [and] available time," but also by "available finances 7 budgeted for a capital project.").) This phase eliminated waterways from trenchless-crossing 8 consideration largely on the basis of expense; as a result, there remained only 13 waterbody crossings 9 in New York for which Constitution planned to investigate a "formal trenchless construction design." 10 (Id. pages 3-2 to 3-4 & tbl.3.2-1.) The Study stated that Phase III, a "geotechnical field analysis" of 11 each of the 13 locations, was in progress. (Id. page 5-1.) Constitution thus planned to use the 12 trenched method for 238 of the 251 New York waterbodies to be crossed. 13 2. NYSDEC Comments and the FEIS 14 In connection with FERC's announcement of a planned EIS for the Constitution 15 pipeline--and its subsequent draft EIS ("DEIS")--NYSDEC submitted numerous letters to FERC. The 16 first noted that NYSDEC's preferred method for crossing waterbodies is a trenchless method, in 17 particular 18 19 20 21 Horizontal Directional Drilling (HDD) because it has the advantages of minimizing land disturbance, avoiding the need for dewatering of the stream, leaving the immediate stream bed and banks intact, and reducing erosion, sedimentation and Project-induced watercourse instabilities. 22 (November 7, 2012 Letter from NYSDEC to FERC at 3 (emphasis added).) Stating that the DEIS 23 should identify the New York classification of each stream the proposed pipeline would cross, 7 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page8 of 27 1 NYSDEC urged FERC to "evaluate cases where other methods are proposed" and have Constitution 2 "explain why HDD will not work or is not practical for that specific crossing." (Id. (emphasis 3 added).) 4 A May 2013 letter again stated that "NYSDEC's preferred methodology for all stream 5 crossings is . . . (HDD)"; that letter also stated that "[w]ithin stream crossings, pipelines should be 6 buried at least 6' below a stream bottom. Minimum cover depth is not subject to variance based on 7 field conditions." (May 28, 2013 Letter from NYSDEC to FERC ("NYSDEC May 2013 Letter") 8 at 1-2 (emphasis added).) 9 In September 2013, NYSDEC wrote to join a request by the Army Corps for additional 10 analysis of whether the Constitution pipeline could be routed along a certain interstate highway, a 11 route referred to as "Alternative M." (September 25, 2013 Letter from NYSDEC to FERC at 1.) 12 Constitution responded by arguing that Alternative M would have greater environmental impact than 13 Constitution's proposed route and noting likely difficulties in obtaining highway agencies' approvals. 14 (See October 22, 2013 Letter from Constitution to NYSDEC at 2-4.) 15 In 2014, FERC issued its DEIS, which drew criticism from several sources including 16 NYSDEC. (See, e.g., March 24, 2014 Letter from NYSDEC to FERC and Army Corps at 1-2 (urging 17 a revised DEIS to include "geotechnical feasibility studies for all trenchless crossing locations," as 18 well as "site specific blasting plans that include protocols for in-water blasting and the protection of 19 aquatic resources and habitats" (emphasis added)); April 7, 2014 Letter from NYSDEC to FERC and 20 Army Corps ("NYSDEC April 2014 Letter") at 1-5 (adding additional comments and requesting 21 additional analysis of Alternative M which, in NYSDEC's view, would reduce the amount of 22 disturbance of higher-quality waterbodies).) 8 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page9 of 27 1 FERC issued its FEIS in 2014 without significantly expanding on several aspects of 2 the DEIS. It did not address NYSDEC's concern that Constitution had not developed site-specific 3 blasting plans. (See FEIS pages 4-15 to 4-16; DEIS page 4-16.) The FEIS added discussion of two 4 new versions of Alternative M proposed by NYSDEC (see FEIS pages 3-46 to 3-47), but rejected 5 them without analyzing disturbances to high-quality waterbodies (compare id. pages 3-32 to 3-47 with 6 NYSDEC April 2014 Letter at 3-4). And the FEIS stated that the pipeline would be buried 60 inches 7 below streams in normal soil conditions and 24 inches in areas of "consolidated rock" (FEIS 8 page 2-16), as contrasted with the NYSDEC May 2013 Letter's statement that the pipe needed to be 9 buried "at least 6' below a stream bottom" (NYSDEC May 2013 Letter at 2). 10 The FEIS expanded on the DEIS's waterbody crossing information but repeated DEIS 11 explanations for why relatively few crossings were slated to be crossed by trenchless techniques, 12 stating, inter alia, that "[a]ccording to Constitution, trenchless crossing methods are not practical 13 [except in limited circumstances] for waterbody crossings less than 30 feet in width" and that 14 "Constitution indicated that such crossings would be impractical due to minimum length requirements, 15 depth of pipeline considerations, and workspace requirements," and describing the areas that would 16 be required for trenchless crossing "[a]ccording to Constitution" (FEIS page 4-50). The FEIS stated 17 that 18 19 20 21 22 23 24 25 [t]he potential impacts on waterbodies associated with the use of conventional bore or Direct Pipe trenchless crossing methods are considered minimal when compared to other crossing methods. The waterbody and its banks, and typically the entire immediate riparian zone, would not be disturbed by clearing or trenching; rather, the pipe would be installed below the feature. (Id. page 4-56 (emphasis added).) FERC added: We concur with Constitution's assessment that it is not practicable to use trenchless crossing methods where waterbodies were listed as ephemeral or 9 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page10 of 27 1 2 3 intermittent (because these waterbodies are likely to be dry at the time of crossing) or for waterbodies less than 30 feet in width (as extra workspaces needed would offset potential benefits). . . . 4 (FEIS, App'x S, page S-52 (emphases added).) The FEIS noted that Constitution had completed 5 geotechnical feasibility studies at only two New York sites. (See FEIS page 4-4.) 6 B. Proceedings Before NYSDEC 7 While its application to FERC for a certificate of public convenience and necessity was 8 pending, Constitution submitted an application to the Army Corps for a CWA § 404 permit for the 9 discharge of dredged or fill material while constructing the pipeline and to NYSDEC for a CWA 10 § 401 certification that the Project would comply with State water quality standards. In December 11 2014, NYSDEC issued a notice that Constitution's application was complete; but on December 31, 12 it asked Constitution for more information about stream crossings. In January-March 2015, 13 Constitution submitted more information to NYSDEC, and on April 27, 2015, at NYSDEC's request, 14 Constitution withdrew and resubmitted its § 401 application. (Constitution had also withdrawn and 15 resubmitted its § 401 application at NYSDEC's request in May 2014.) 16 1. Stream-Crossing Information Requests by NYSDEC 17 On January 23, 2015, staff from Constitution and NYSDEC met to discuss trenchless 18 stream-crossing methods (see January 14, 2015 email from NYSDEC Project Manager Stephen M. 19 Tomasik to Constitution engineering consultant Keith Silliman; January 27, 2015 email from Tomasik 20 to Constitution Environmental Project Mananger Lynda Schubring ("NYSDEC January 27, 2015 21 email")). Prior to that meeting, Constitution wrote to NYSDEC stating that it had 10 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page11 of 27 1 2 3 4 5 6 7 8 conducted subsurface geotechnical investigations at the majority of the proposed . . . (HDD) and . . . (DP) trenchless locations. Results of the subsurface geotechnical investigations revealed crossing locations that present a high risk of failure if a trenchless method is used. As a result, trenchless crossing locations with a high risk of failure are not feasible and have been modified to a dry open cut design. Since the last . . . submissions to the USACE, three (3) HDD or DP locations affecting six (6) wetlands or waterbodies have changed to an open cut construction method . . . . 9 (January 22, 2015 Letter from Schubring to Tomasik at 1.) Constitution also stated that six other 10 originally proposed trenchless crossings would be crossed by a trenched method, "to address various 11 concerns raised by [state and local] authorities relative to the trenchless crossings of specific public 12 roadways and associated infrastructure." (Id. at 2.) After the January 23 meeting, NYSDEC 13 requested additional documents that Constitution personnel had said informed its decision to use the 14 trenched crossing method at two locations, as well as "information about stream crossings that we 15 requested on 12/31/2014." (NYSDEC January 27, 2015 email). 16 In response, Constitution submitted feasibility evaluations based on geotechnical 17 studies for four locations: two wetlands crossings and two waterbody crossings. One of the 18 waterbody feasibility evaluations concluded that using either HDD or DP was infeasible due to 19 subsurface soil conditions; the other did not address the feasibility of trenchless crossing methods, and 20 instead discussed only a contingency open-cut crossing to be used if the proposed DP crossing failed. 21 In February 2015, Constitution submitted to NYSDEC a document titled "Draft 22 Trenchless Feasibility Study Edits" ("Constitution 2015 Feasibility Draft") that appears to be a version 23 of part of the 2013 trenchless feasibility study that Constitution had submitted to FERC, merely 24 expanding on the manner in which each trenchless method operates. Again there was no discussion 25 of stream crossings site-by-site. The Constitution 2015 Feasibility Draft stated that 26 Constitution recognizes that, in general, performing . . . (HDD) for streams 11 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page12 of 27 1 2 3 4 less than 30 feet in width causes greater net environmental impacts than a dry open cut method and this threshold is an industry recognized standard. Constitution has not identified any NYSDEC regulation, formally adopted policy or guidance document that would warrant deviating from this standard. 5 (Id. at 1 (emphases added).) It also discussed the Direct Pipe method, stating that "it is likely that 6 additional forest will require clearing to perform DP for most of the protected stream crossings," and 7 that "[m]any" streams are in valleys whose slopes make the DP method infeasible. (Id. at 2-3 8 (emphases added).) In addition, the Constitution 2015 Feasibility Draft stated that DP technology is 9 of "limited availability," leading Constitution to conclude that using "DP technology for . . . streams 10 less than 30 feet in width is not a realistic or viable expectation within a reasonable period of time." 11 (Id. at 3 (emphasis added).) 12 In March 2015, NYSDEC sent Constitution a list of 20 waterbody locations that 13 NYSDEC "wants crossed via HDD," stating that NYSDEC "is still expecting an evaluation as to 14 whether an HDD is technically feasible for each of these streams." (March 17, 2015 email from 15 NYSDEC Major Project Management Unit Chief Christopher M. Hogan to Silliman (emphasis 16 added).) In April 2015, as indicated above, Constitution withdrew and resubmitted its § 401 WQC 17 request. 18 2. Subsequent Discussions 19 In May 2015, NYSDEC noted that it had agreed to "eliminate" four streams from 20 "further consideration for trenchless crossing methods." (May 22, 2015 email from Tomasik to 21 Schubring, Silliman, et al.) 22 In July 2015, a member of NYSDEC's staff emailed to certain Army Corps staff 23 members a "Confidential" message attaching a "VERY PRELIMINARY version of a Constitution 12 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page13 of 27 1 permit" (July 20, 2015 email from Tomasik to Kevin J. Bruce et al., Army Corps), which included a 2 table of 19 locations that "shall be crossed using a trenchless construction method"--unless an 3 "experienced and qualified engineer" concludes that the techniques are "not constructible or not 4 feasible" (Confidential Draft NYSDEC Certification Conditions at 17). The draft, however, required 5 Constitution, "[p]rior to beginning construction of any trenchless stream crossing," to "submit a[] 6 . . . 'Trenchless Crossing Plan' for each trenchless stream crossing," including "detailed engineering 7 plans" for each location. (Id. at 18 (emphases added).) 8 In September 2015, Constitution submitted to NYSDEC an Environmental 9 Construction Plan, attached to which was a Blasting Plan. (See Constitution, Environmental 10 Construction Plan 50 (Aug. 2015).) This plan listed 253 "[a]reas of shallow depth to bedrock crossed 11 by the [pipeline]" in New York, but stated that "[a] final determination on the need for blasting will 12 be made at the time of construction." (Constitution, Blasting Plan (Aug. 2015) ("Blasting Plan") 13 pages 1-1, 1-2 & tbl.1.2-2, 4-1.) The Blasting Plan identified regulations and a permit that would 14 govern blasting in Pennsylvania, but stated that "[a]ll blasting operations in New York will be 15 conducted in accordance with an in-stream b[l]asting protocol to be prepared by Constitution." (Id. 16 page 4-1 (emphasis added).) 17 C. NYSDEC's Decision Denying § 401 Certification 18 In a 14-page letter to Constitution dated April 22, 2016, NYSDEC denied 19 Constitution's application for CWA § 401 certification ("NYSDEC Decision" or "Decision"), stating 20 that "the Application fails in a meaningful way to address the significant water resource impacts that 21 could occur from this Project and has failed to provide sufficient information to demonstrate 13 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page14 of 27 1 compliance with New York State water quality standards," NYSDEC Decision at 1. Although also 2 noting the lack of adequate information as to such issues as the feasibility of the Alternative M route, 3 blasting information, pipe burial depth, and wetlands crossings, see, e.g., id. at 11-14, the Decision 4 focused principally on Constitution's failure to provide information with respect to stream crossings. 5 NYSDEC noted that Constitution's Project "would disturb a total of 251 streams . . . , 6 87 of which support trout or trout spawning," and that "[c]umulatively, construction would disturb 7 a total of 3,161 linear feet of streams and result in a combined total of 5.09 acres of temporary stream 8 disturbance impacts." NYSDEC Decision at 8. It stated that although 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 [f]rom inception of its review of the Application, NYSDEC directed Constitution to demonstrate compliance with State water quality standards and required site-specific information for each of the 251 streams impacted by the Project[, and] NYSDEC informed Constitution that all 251 stream crossings must be evaluated for environmental impacts and that trenchless technology was the preferred method for stream crossing[, and that t]his information was conveyed to Constitution and FERC on numerous occasions since November 2012[,] . . . Constitution has not supplied the Department with the necessary information for decision making. Id. (emphasis in original). The Decision stated that because some form of trenchless technology is the "most protective method for stream crossings," NYSDEC directed Constitution to determine whether a trenchless technology was constructible for each stream crossing. On a number of occasions NYSDEC identified the need to provide information so that it could evaluate trenchless stream installation methods (see Table 2, below); however, Constitution has not provided sufficient information . . . . Id. (footnote omitted) (emphasis added). 27 Table 2 in the Decision principally chronicled NYSDEC's requests of Constitution-- 28 both directly and indirectly in its submissions to FERC--and noted Constitution's resistance, including 14 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page15 of 27 1 the following: 2 3 4 # In June 2012, "NYSDEC stated in a letter to Constitution that for protected streams and wetlands, trenchless technology is the preferred method for crossing and should be considered for all such crossings (emphasis added)." 5 6 7 8 9 # On November 7, 2012, "[i]n comments to FERC, NYSDEC stated that for streams and wetlands the preferred method for crossing is trenchless technology," and that as to each crossing where another method is proposed "Constitution should explain why trenchless crossing technology will not work or is not practical for that specific crossing." 10 11 12 # On April 9, 2013, "FERC[] . . . directed Constitution to address all of the comments filed in the public record by other agencies . . . including all comments from the NYSDEC." 13 14 15 16 # On May 28, 2013, at a "[m]eeting" of "Constitution and NYSDEC staff . . . NYSDEC reiterate[d] that acceptable trenchless technology was the preferred installation method and that stream crossings should be reviewed for feasibility of using those technologies." 17 18 19 20 # In July and August 2013, on "[f]ield visits of proposed stream crossings prior to permit applications to the Department[, a]t each crossing, NYSDEC emphasized to Constitution staff that trenchless technology is preferred/most protective." 21 22 23 # In its November 2013 Trenchless Feasibility Study, Constitution "arbitrarily eliminated from any consideration for trenchless crossing methods" "all streams less than 30' wide." 24 25 26 27 28 # On December 31, 2014, at a meeting with Constitution staff, "NYSDEC indicated that the Trenchless Feasibility Study was inadequate, e.g. provided insufficient justification and removed all streams less than 30 feet in width from analysis." NYSDEC gave Constitution "an informational request table including required technical information." 29 30 # On January 13, 2015, an "Army Corps of Engineers letter reiterate[d] a request for a feasibility analysis of trenchless crossings." 31 32 33 34 35 # At a January 23, 2015 "[m]eeting between Constitution and NYSDEC staff . . . Constitution stated it was unable to complete the [informational request] table [it received from NYSDEC] on December 31, 2014[]. NYSDEC staff indicated that the justification for stream crossing methods was insufficient and that appropriate site specific information must be provided." 15 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page16 of 27 1 2 3 # In a January 28, 2015 "[c]onference call[,] NYSDEC reiterated its request for a site specific analysis of trenchless stream crossings for all streams including those under 30 feet wide." 4 5 6 7 # On February 5, 2015, "Constitution provided an updated example of a trenchless feasibility study but that example continued to exclude streams up to 30 feet wide from analysis and did not provide detailed information of the majority of streams." 8 NYSDEC Decision at 9-10 (emphases added). 9 Although the Decision's Table 2 ended with the February 2015 entry, the Decision 10 noted that Constitution's "unwillingness to provide a complete and thorough[] Trenchless Feasibility 11 Study" persisted: 12 13 14 15 16 17 18 [I]n May 2015, Constitution provided detailed project plans for 25 potential trenchless crossings, but only two of those plans were based on full geotechnical borings that are necessary to evaluate the potential success of a trenchless design. Detailed project plans including full geotechnical borings for the remaining stream crossings have not been provided to the Department. Id. at 11 (emphasis added). The NYSDEC Decision stated that 19 20 21 22 23 24 25 26 27 [d]ue to the lack of detailed project plans, including geotechnical borings, the Department has determined to deny Constitution's WQC Application because the supporting materials supplied by Constitution do not provide sufficient information for each stream crossing to demonstrate compliance with applicable narrative water quality standards for turbidity and preservation of best usages of affected water bodies. Specifically, the Application lacks sufficient information to demonstrate that the Project will result in no increase that will cause a substantial visible contrast to natural conditions.10 28 29 30 31 32 33 Furthermore, the Application remains deficient in that it does not contain sufficient information to demonstrate compliance with 6 NYCRR Part 701 setting forth conditions applying to best usages of all water classifications. Specifically, "the discharge of sewage, industrial waste or other wastes shall not cause impairment of the best usages of the receiving water as specified by the water classifications at the location of the discharge and at other locations 16 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page17 of 27 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 that may be affected by such discharge."11 10 11 6 NYCRR § 703.2. 6 NYCRR § 701.1. NYSDEC Decision at 12 & nn.10-11. The Decision added that [c]umulatively, impacts to both small and large streams from the construction and operation of the Project can be profound and include loss of available habitat, changes in thermal conditions, increased erosion, creation of stream instability and turbidity, impairment of best usages, as well as watershed-wide impacts resulting from placement of the pipeline across water bodies in remote and rural areas (See Project Description and Environmental Impacts Section, above). Because the Department's review concludes that Constitution did not provide sufficient detailed information including site specific project plans regarding stream crossings (e.g. geotechnical borings) the Department has determined to deny Constitution's WQC Application for failure to provide reasonable assurance that each stream crossing will be conducted in compliance with 6 NYCRR §608.9. 17 NYSDEC Decision at 12; see 6 N.Y.C.R.R. § 608.9(a)(2) ("The applicant" for a CWA § 401 18 certification "must demonstrate compliance with sections 301-303, 306 and 307 of the Federal Water 19 Pollution Control Act, as implemented by . . . water quality standards and thermal discharge criteria 20 set forth in Parts 701, 702, 703 and 704 of this Title . . . ."). 21 II. DISCUSSION 22 In its petition for review (or "Petition"), Constitution contends principally (1) that 23 NYSDEC failed to issue its Decision within a reasonable time as required by § 401 and thus must be 24 required to inform USACE that NYSDEC has waived its right to rule on Constitution's application 25 for a WQC, thereby enabling the Army Corps to grant Constitution a permit for its pipeline Project, 26 or (2) alternatively, that Constitution submitted sufficient information and that NYSDEC's decision 17 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page18 of 27 1 should be vacated on the ground that its denial of the application was arbitrary, capricious, and ultra 2 vires, and that NYSDEC should be ordered to grant the requested § 401 certification. For the reasons 3 that follow, we (1) conclude that Constitution's first contention, which would have us treat NYSDEC's 4 Decision as an act that is void, lies beyond the jurisdiction of this Court, and (2) conclude that 5 NYSDEC's Decision was not ultra vires, arbitrary, or capricious. 6 A. Constitution's Argument that NYSDEC Waived Its § 401 Authority 7 The Natural Gas Act (or "NGA"), 15 U.S.C. §§ 717-717z, sets out provisions with 8 respect to, inter alia, the construction of transportation facilities for natural gas, see id. § 717f. Such 9 projects are also subject to restrictions under other federal statutes, including provisions of the Clean 10 Water Act, see, e.g., id. § 717b(d)(3). Section 401 of the CWA requires an applicant for a federal 11 permit to conduct any activity that "may result in any discharge into the navigable waters" of the 12 United States to obtain "a certification from the State in which the discharge . . . will originate . . . that 13 any such discharge will comply with," inter alia, the state's water quality standards. 33 U.S.C. 14 § 1341(a)(1). 15 As to petitions for review relating to such applications, § 717r of the NGA divides 16 jurisdiction between the Circuit in which the facility is proposed to be constructed and the United 17 States Court of Appeals for the District of Columbia Circuit. It states, in pertinent part, as follows: 18 19 20 21 22 23 24 (1) In general The United States Court of Appeals for the circuit in which a facility subject to . . . section 717f of this title is proposed to be constructed . . . shall have original and exclusive jurisdiction over any civil action for the review of an order or action of a Federal agency (other than [FERC]) or State administrative agency acting pursuant to Federal law to issue, condition, or deny any permit, license, concurrence, or approval (hereinafter collectively 18 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page19 of 27 1 referred to as "permit") required under Federal law . . . . 2 (2) Agency delay 3 4 5 6 7 The United States Court of Appeals for the District of Columbia shall have original and exclusive jurisdiction over any civil action for the review of an alleged failure to act by a Federal agency (other than [FERC]) or State administrative agency acting pursuant to Federal law to issue, condition, or deny any permit required under Federal law . . . . 8 15 U.S.C. §§ 717r(d)(1)-(2) (emphases added). We regard subsection (2)--titled "Agency delay"--as 9 encompassing not only "an alleged failure to act" but also an allegation that a failure to act within a 10 mandated time period should be treated as a failure to act. This is the nature of Constitution's first 11 argument. 12 Constitution points out that CWA § 401 provides that "[i]f" a "State . . . agency" from 13 which an applicant for a federal permit has sought a water quality certification "fails or refuses to act 14 on [the] request for certification, within a reasonable period of time (which shall not exceed one year) 15 after receipt of such request, the certification requirements of this subsection shall be waived with 16 respect to such Federal application." 33 U.S.C. § 1341(a)(1). Constitution argues that NYSDEC did 17 not issue its Decision until 32 months after Constitution submitted its initial application, 16 months 18 after NYSDEC issued notice that that initial application was complete, 15 months after the deadline 19 imposed by FERC, nearly a year ("359 days") after Constitution's 2015 withdrawal-and-resubmission 20 of its application--and eight months after Constitution claims it was advised by NYSDEC that 21 NYSDEC "had everything it needed to issue a Section 401 Certification." (Constitution brief in 22 support of Petition at 28-29.) Constitution argues that NYSDEC "waived its right" to rule on the 23 certification application and must be required to so notify the Army Corps. (Id. at 37.) 24 We note first that there is nothing in the administrative record to show that NYSDEC 19 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page20 of 27 1 received the information it had consistently and explicitly requested over the course of several years-- 2 much less anything to support Constitution's claim that NYSDEC said "it had" all of the information 3 it required "to issue" the requested certification (id. at 29). Although Constitution proffered in this 4 Court non-record declarations from certain of its personnel, those "outside-the-record declarations and 5 associated portions of [Constitution]'s brief" were stricken. Constitution Pipeline Co. v. Seggos, No. 6 16-1568 (2d Cir. Oct. 3, 2016). 7 Second, Constitution's "waive[r]" argument is that the NYSDEC Decision must be 8 treated as a nullity by reason of NYSDEC's "failing to act within the prescribed time period under the 9 CWA" (Constitution brief in support of Petition at 37 (emphasis added)). Such a failure-to-act claim 10 is one over which the District of Columbia Circuit would have "exclusive" jurisdiction, 15 U.S.C. 11 § 717r(d)(2). 12 Environmental Management, 524 F.3d 1330, 1332 (D.C. Cir. 2008). Accordingly, we dismiss 13 Constitution's timeliness argument for lack of jurisdiction. 14 B. Constitution's Challenge to the Merits of NYSDEC's Decision See generally Weaver's Cove Energy, LLC v. Rhode Island Department of 15 Judicial review of an administrative agency's denial of a CWA § 401 certificate is 16 limited to grounds set forth in the Administrative Procedure Act, 5 U.S.C. §§ 701-706. We review 17 the agency's interpretation of federal law de novo; if the agency correctly interpreted federal law, we 18 review its factual determinations under the arbitrary-and-capricious standard, see id. § 706(2)(A); 19 Islander East Pipeline Co. v. McCarthy, 525 F.3d 141, 150 (2d Cir. 2008) ("Islander East II"); 20 Islander East Pipeline Co. v. Connecticut Department of Environmental Protection, 482 F.3d 79, 94 21 (2d Cir. 2006) ("Islander East I"). 20 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page21 of 27 1 1. Federal Law 2 Constitution argues that as a matter of law, NYSDEC's "jurisdiction to review"--and 3 "in effect, veto"--FERC determinations is preempted by FERC's performance of its obligations under 4 the National Environmental Policy Act ("NEPA"), 42 U.S.C. §§ 4321-4370h, to prepare a DEIS and 5 a FEIS. (Constitution brief in support of Petition at 37, 39.) We disagree that NYSDEC's action was 6 preempted. 7 Although NEPA requires federal-agency review of virtually any possible 8 environmental effect that a proposed action may have, see generally 40 C.F.R. § 1502.16, it does not 9 impose substantive standards. See Robertson v. Methow Valley Citizens Council, 490 U.S. 332, 350 10 (1989). "[T]hrough a set of action-forcing procedures," NEPA "require[s] that agencies take a hard 11 look at environmental consequences," but it is "well settled that NEPA itself does not mandate 12 particular results[; it] simply prescribes the necessary process." Id. (internal quotation marks omitted). 13 Thus, NEPA states, in pertinent part, that "[n]othing in section 4332 or 4333 of this title shall in any 14 way affect the specific statutory obligations of any Federal agency . . . to act, or refrain from acting 15 contingent upon the recommendations or certification of any . . . State agency." 42 U.S.C. § 4334. 16 We note also that while the Natural Gas Act generally preempts state laws, it states that 17 "[e]xcept as specifically provided[,] . . . nothing" in the NGA "affects the rights of States under . . . 18 the [CWA] (33 U.S.C. § 1251 et seq.)," 15 U.S.C. § 717b(d). CWA § 511, in turn, preserves the 19 states' authority to determine issues of a planned project's effect on water quality. See 33 U.S.C. 20 § 1371(c)(2)(A). CWA § 401(a)(1) requires that an entity such as Constitution, proposing to construct 21 an interstate pipeline, obtain from each state in which the pipeline is to be constructed a certification 22 that "any . . . discharge" from a proposed activity "will comply with the applicable provisions of [33 21 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page22 of 27 1 U.S.C. §§] 1311, 1312, 1313, 1316, and 1317." 33 U.S.C. § 1341(a)(1). Sections 1311, 1312, 1316, 2 and 1317 establish, and allow the Environmental Protection Agency ("EPA") to establish, standards 3 governing numerous aspects of water quality; and § 1313 allows states to develop their own water 4 quality standards and submit them to the EPA for approval. If the EPA approves a state's water 5 quality standards, it publishes a notice of approval and they become the state's EPA-approved 6 standards, regulating water quality in that state. See 33 U.S.C. §§ 1313(a), (c). 7 The New York State water quality standards, approved by the EPA, see generally 42 8 Fed. Reg. 56,786, 56,790 (Oct. 28, 1977), are found in 6 N.Y.C.R.R. parts 701 to 704, and were 9 invoked by the NYSDEC Decision, which stated that "[d]enial of a WQC may occur when an 10 application fails to contain sufficient information to determine whether the application demonstrates 11 compliance with the above stated State water quality standards and other applicable State statutes and 12 regulations due to insufficient information." NYSDEC Decision at 7; see also id. at 12 nn.10-11 and 13 accompanying text (quoted in Part I.C. above). The State standards classify waterbodies in terms of, 14 inter alia, potability and their suitability for various activities such as swimming and fishing, see 6 15 N.Y.C.R.R. pt. 701; they set standards for characteristics such as water odor, color, and turbidity, see 16 id. pt. 703; and they regulate thermal discharges into waterbodies, see id. pt. 704. 17 Thus, the relevant federal statutes entitled NYSDEC to conduct its own review of the 18 Constitution Project's likely effects on New York waterbodies and whether those effects would 19 comply with the State's water quality standards. 20 CWA § 401(a)(1), as pertinent here, states that "[n]o license or permit shall be granted 21 if [a § 401] certification has been denied by the State," 33 U.S.C. § 1341(a)(1). Thus, we have indeed 22 referred to § 401 as "a statutory scheme whereby a single state agency effectively vetoes an energy 22 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page23 of 27 1 pipeline that has secured approval from a host of other federal and state agencies." Islander East II, 2 525 F.3d at 164 (emphases added); accord Keating v. FERC, 927 F.2d 616, 622 (D.C. Cir. 1991) 3 ("Through [the § 401 certification] requirement, Congress intended that the states would retain the 4 power to block, for environmental reasons, local water projects that might otherwise win federal 5 approval." (emphasis added)). 6 Constitution also argues that NYSDEC's demands for information with regard to, e.g., 7 possible alternative routes for the planned pipeline (see, e.g., NYSDEC Decision at 3 (NYSDEC 8 "asked Constitution to analyze alternative routes that could have avoided or minimized impacts to an 9 extensive group of water resources")), as well as Constitution's planned blasting sites and the depth 10 at which the pipe would be buried, exceeded NYSDEC's authority (Constitution brief in support of 11 Petition at 38). We need not address all of these contentions. A state's consideration of a possible 12 alternative route that would result in less substantial impact on its waterbodies is plainly within the 13 state's authority. See, e.g., Islander East II, 525 F.3d at 151-52. And where an agency decision is 14 sufficiently supported by even as little as a single cognizable rationale, that rationale, "by itself, 15 warrants our denial of [a] petition" for review under the arbitrary-and-capricious standard of review. 16 See, e.g., id. at 158. 17 2. Application of the Arbitrary-and-Capricious Standard 18 Under the arbitrary-and-capricious standard, "[a] reviewing court may not itself weigh 19 the evidence or substitute its judgment for that of the agency." Islander East II, 525 F.3d at 150. 20 "Rather," we "consider[] whether the agency 'relied on factors which Congress has not intended it to 23 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page24 of 27 1 consider, entirely failed to consider an important aspect of the problem, offered an explanation for its 2 decision that runs counter to the evidence before the agency, or is so implausible that it could not be 3 ascribed to a difference in view or the product of agency expertise.'" Id. at 150-51 (quoting Motor 4 Vehicle Manufacturers Ass'n of the United States, Inc. v. State Farm Mutual Automobile Insurance 5 Co., 463 U.S. 29, 43 (1983) ("State Farm")). 6 7 8 9 10 [W]ithin the prescribed narrow sphere, judicial inquiry must be searching and careful. . . . Notably, a court must be satisfied from the record that the agency . . . examine[d] the relevant data and articulate[d] a satisfactory explanation for its action. . . . Further, the agency's decision must reveal a rational connection between the facts found and the choice made. 11 Islander East II, 525 F.3d at 151 (internal quotation marks omitted). If there is "sufficient evidence 12 in the record to provide rational support for the choice made by the agency," we must uphold its 13 decision. Id. at 152. 14 Usually, the agency's choice concerns whether the applicant's submission of the 15 relevant information warrants the granting of the application. In the present case, as summarized in 16 Part I.C. above, NYSDEC denied Constitution's application because Constitution refused to provide 17 information that NYSDEC had repeatedly requested with regard to, inter alia, issues such as those 18 just discussed in Part II.B.1. above, and issues as to the feasibility, site-by-site, of trenchless methods 19 for most of the 251 stream crossings planned in New York. Constitution does not contend that those 20 requests were not made. Indeed, in its own brief in this Court, Constitution acknowledges that the 21 NYSDEC Decision (the "Denial") explained that NYSDEC had requested but had not received 22 sufficient information with regard to: 23 24 Ë construction methods and site-specific project plans for stream crossings (Denial at 8-11 . . .); 25 Ë alternative routes (Id. at 11 . . .); 24 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page25 of 27 1 Ë pipeline burial depth in stream beds (Id. at 12-13 . . .); 2 3 Ë procedures and safety measures Constitution would follow in the event that blasting is required (Id. at 13 . . .); 4 5 Ë Constitution's plans to avoid, minimize, or mitigate discharges to navigable waters and wetlands (Id. at 13-14 . . .); and 6 Ë cumulative impacts (Id. at 3, 5, 7, 14 . . .). 7 (Constitution brief in support of Petition at 21-22.) Nowhere does Constitution claim to have 8 provided the above categories of information; rather, it insists that it provided NYSDEC with 9 "sufficient" information (id. at 52-62) because use of trenchless crossing methods for streams less than 10 30 feet wide is not "an industry recognized standard" (Constitution 2015 Feasibility Draft at 1). 11 However, in order to show that an agency's decision--or its request for additional 12 information as to alternative methods--is arbitrary and capricious, "it is not enough that the regulated 13 industry has eschewed a given [technology]." State Farm, 463 U.S. at 49. Industry preferences do 14 not circumscribe environmental relevance. 15 In Marsh v. Oregon Natural Resources Council, 490 U.S. 360 (1989), the Supreme 16 Court considered whether a federal agency, presented with new evidence, should have been required 17 to file a new supplemental environmental impact statement; the Court stated that the matter of whether 18 additional information is "significant" is "a classic example of a factual dispute the resolution of 19 which implicates substantial agency expertise," as to which the courts "must defer to the informed 20 discretion of the responsible . . . agencies," id. at 376-77 (internal quotation marks omitted). We 21 cannot conclude that any less deference is due an agency's determination that it should not grant a 22 permit application where it has already determined that additional information is needed, and the 23 applicant refuses to supply it. Cf. University of Iowa Hospitals & Clinics v. Shalala, 180 F.3d 943, 25 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page26 of 27 1 955 (8th Cir. 1999) (where agency regulations required substantiation of costs for which 2 reimbursement was sought, denial of reimbursement based on inadequate documentation was not 3 arbitrary and capricious); Mendoza v. Secretary, DHS, 851 F.3d 1348, 1356 (11th Cir. 2017) (denial 4 of visa application where applicants declined to answer relevant questions relating to eligibility was 5 not arbitrary and capricious; the applicants "were free to refuse to answer [the agency's] questions 6 . . . but they did so at their own peril"). Indeed, an agency's decision may be found "arbitrary and 7 capricious" for "issuing a permit with insufficient information." Utahns For Better Transportation 8 v. United States Department of Transportation, 305 F.3d 1152, 1192 (10th Cir. 2002) (emphasis 9 added). 10 Here, the record amply shows, inter alia, that Constitution persistently refused to 11 provide information as to possible alternative routes for its proposed pipeline or site-by-site 12 information as to the feasibility of trenchless crossing methods for streams less than 30 feet wide--i.e., 13 for the vast majority of the 251 New York waterbodies to be crossed by its pipeline--and that it 14 provided geotechnical data for only two of the waterbodies. 15 In sum, NYSDEC is responsible for evaluating the environmental impacts of a 16 proposed pipeline on New York waterbodies in light of the State's water quality standards. Applying 17 the arbitrary-and-capricious standard of review, we defer to NYSDEC's expertise as to the 18 significance of the information requested from Constitution, given the record evidence supporting the 19 relevance of that information to NYSDEC's certification determination. We conclude that the denial 20 of the § 401 certification after Constitution refused to provide relevant information, despite repeated 21 NYSDEC requests, was not arbitrary or capricious. 26 Case 16-1568, Document 240-1, 08/18/2017, 2103921, Page27 of 27 1 CONCLUSION 2 We have considered all of Constitution's arguments and have found in them no basis 3 for granting the petition for review. Insofar as the petition contends that the NYSDEC Decision is 4 a nullity on the ground that it was untimely, the petition is dismissed for lack of jurisdiction; to the 5 extent that the petition challenges the NYSDEC Decision on the merits, the petition is denied. 27

Disclaimer: Justia Dockets & Filings provides public litigation records from the federal appellate and district courts. These filings and docket sheets should not be considered findings of fact or liability, nor do they necessarily reflect the view of Justia.

Why Is My Information Online?